In today’s society, letters of commitment are used more and more often. Letters of commitment are usually contracts that require a written form, and the commitment must also be in writing. So how is a general commitment letter written? The following are 9 performance commitment letters that I have carefully compiled. You are welcome to read them. I hope you will like them. Performance Commitment Letter 1

Performance Commitment Letter

Henan Shenglong Architectural Decoration Design Engineering Co., Ltd.:

After internal competition, in the name of the project leader Regarding the decoration and renovation project undertaken, I now make the following commitments to the company:

1. I promise to fulfill the contents of the project contract signed by Henan Shenglong Architectural Decoration Design Engineering Co., Ltd. and the owner, and the contract signed by our company. All stipulations in the internal contracting contract shall be strictly implemented, including construction management specifications, safety operating procedures, fire safety regulations, quality and environmental protection requirements, and the completion of the decoration regulations and tasks until qualified acceptance:

2. Any incidents involving engineering projects I am solely responsible for paying and handling any economic and civil liabilities that may arise before and after signing an internal contract contract with our company, such as labor costs, material fees, rental fees, and external debts. No relationship whatsoever:

3. I am fully aware of the illegal behavior of compiling, imitating, and forging any company documents and seals without the company’s authorization and damaging the company’s image and causing adverse effects. Upon verification, the company will have all project funds confiscated and be held accountable for relevant legal liabilities.

4. I further understand that in accordance with the provisions of the Construction Market Management Law, the quality responsibility for the project tasks I have undertaken will not be released after the termination of the contract or the expiration of the warranty period

Responsibility and safety responsibility.

5. During the construction process, Party B shall be fully responsible for any fines, deductions and other matters incurred by the builder caused by Party B, and shall be deducted from the project payment in advance.

6. Due to my own reasons, I promise that in case of emergency, the company has the right to preemptively withdraw from the project payment for violations of safety operating standards and other barbaric construction and unreasonable default of any project payment to other parties. Pay.

I hereby promise!

Pledger:

ID card number where ID card is affixed:

Current address:

Contact information:

Emergency contact person: Date:

Performance Commitment Part 2

On July **, 20xx, the ** contract section was held at the ** contract section project management department Production scheduling meeting. **The project manager** of the contract section, the chief engineer**, the ar*resident engineer**, and the management office** attended the meeting. According to the spirit of the Fuji Expressway Participating Unit Meeting and Project Management Work Meeting organized by the project office on July 10, 20xx and the work goals of carrying out the "100 Days of Work to Vigorously Promote Standardized Construction" activity, combined with the time of this project Due to the characteristics of tight, heavy tasks, high standards and great difficulty, we fully grasped the adverse weather and took advantage of the favorable weather to comprehensively organize the construction. On behalf of the ** contract section, the project manager ** solemnly made the following commitments on the current overall construction arrangements:

1. The opening and hardening of vertical and horizontal construction access roads (a2, a7, a8 steel trestles) have been completed. The percentage of ** kilometers in the total amount is **, and the requisition of the spoil site has been completed (or planned for 20xx The requisition of the spoil site will be completed at the ** pile number on ** month **, 20xx), and the longitudinal construction access road that can ensure the smooth passage of the concrete truck and the lateral construction road to the concrete mixing station in the entire contract section will be opened before ** month **, 20xx. The construction sidewalks should be hardened, watered and cleaned to avoid environmental pollution.

2. Construction of concrete mixing station, steel bar processing plant, small cover plate prefabrication yard, and beam slab prefabrication yard (with planning drawings for each temporary construction attached)

1. No. 1 concrete mixing station The station is located at ** stake number, covers an area of ??** square meters, has a hardened area of ??** square meters, has a silo area of ??** square meters, has a partition wall height of ** meters, can store ** cubic materials, and the mixer is ** model and can be produced per hour. The volume is ** cubic meters. *** has ** concrete transport trucks and ** concrete pump trucks. They mainly supply concrete for ** structures. The concrete volume is ** cubic meters. In 20xx** It will be completed and put into use before **, the No. 1 concrete mixing station team *** has ** people

The station manager is ***; the No. 2 concrete mixing station is located at the ** pile number and covers an area ** square meters, hardened area ** square meters, silo area ** square meters, partition height ** meters, can store ** cubic materials, the mixer is ** model, the production capacity per hour is ** cubic meters, *** There are ** concrete transport trucks and ** concrete pump trucks, which mainly supply concrete for ** structures. The concrete volume is ** cubic meters. They will be completed and put into use before ** month **, 20xx. No. 2 concrete The mixing station team *** has ** people and the station manager is ***.

2. The CNC steel bar processing machine arrived at the site on ** month **, 20xx. The No. 1 steel bar processing plant is located at ** stake number, covering an area of ??** square meters, and a hardened area of ??** square meters, mainly * *The structure provides steel bar processing. It was completed and put into use before ** month **, 20xx. The No. 1 steel bar processing plant has a team of ***** people, including **** skilled workers and the factory director is ***; No. 2 steel bar processing plant The factory is located at ** stake number, covers an area of ??** square meters, and has a hardened area of ??** square meters. It mainly provides steel bar processing for ** structures. It was completed and put into use on ** month ** of 20xx. The team of No. 2 steel bar processing plant ** *** people, including the skilled worker *** and the factory director are ***.

3. The small cover plate prefabrication site is located at the ** stake number, covering an area of ??** square meters and a hardened area of ??** square meters. It was completed and put into use on ** month ** of 20xx. The small cover plate team* **There is a ** person and the person in charge is ***, and all small covers were produced on *month**, 20xx. 4. The No. 1 bridge prefabrication site is located at the ** stake number, covering an area of ??** square meters and a hardened area of ??** square meters. Among them, there are ** T-beam bases and ** sets of T-beam templates. *** is produced for the ** bridge. ** pieces of T-beams, average daily production of ** pieces of T-beams, were completed before **, month **, 20xx, the first piece of t-beams were produced on **, month **, and the plate beam base ** is ** Bridge produces ** plate girders. The plate girder formwork is ** sets. The average daily production is ** plate girders. It will be completed before ** month ** in 20xx and the first plate will be produced on ** month **. Beam, the No. 1 beam field team is ***** person,

The field director is **; the No. 2 bridge prefabricated field is located at the ** pile number, covering an area of ??** square meters, and the hardened area is ** square meters. , including ** T-beam bases, ** sets of T-beam formwork, *** produces ** T-beams for ** bridge, average daily production of ** T-beams, and was completed before ** month **, 20xx , the first T-beam was produced on ** month **, the plate beam base ** was produced for the ** bridge, and the plate beam formwork was ** sets, and the average daily production of plate beams was ** This piece was completed before ** on **, 20xx. The first plate beam was produced on ** on **. The No. 2 beam field team consisted of ***** people and the field director was **;

3. Signing of raw material supply contract (contract agreement attached to the signed contract)

1. There are ** steel manufacturers that have been signed, and there are ** manufacturers planned to be signed on ** month ** in 20xx. **.

2. There are ** cement manufacturers that have been signed, and there are ** manufacturers that are planned to be signed on ** month **, 20xx.

3. There are ** manufacturers of external admixtures that have been signed, and there are ** manufacturers that are planned to be signed on ** month **, 20xx.

….

IV. Subgrade earthwork construction arrangements

Subgrade No. 1 work area: the work area director is **, the on-site technical person in charge is **, and the on-site management personnel* * people, *** need to complete ** million earthworks, the main supporting machinery is: excavator **, loader **, bulldozer **, road roller **, 1 grader, ** dump truck ....., it is expected that ** earthwork will be completed every day of the month, and it will be completed on ** month **, 20xx.

Subgrade Second Work Area: The work area director is **, the on-site technical person in charge is **, on-site management

There are ** personnel, *** need to complete ** million earth and stone supporting main machinery There are: ** excavators, ** loaders, ** bulldozers, ** road rollers, 1 grader, ** dump trucks..., it is expected to complete ** earthworks every day, 20xx* It can be completed on *month**.

….

5. Construction Arrangements for Bridge Pile Foundation and Substructure

1. Bridge Pile Foundation and Substructure Team 1: The leader is **, on-site Technical person in charge **, on-site management personnel **. ***There are **pile foundations for **bridge, ***needs **drilling rig, **drilling rig has arrived, plans to arrive at **drilling rig on **month **, ***needs electricity **KW, temporary power consumption has been completed (or when it will be connected) **KW, self-provided generator set **, power **KW, it is estimated that each hole will take ** days, planned for October 30, 20xx Completed ** pile foundations, accounting for ** of the total pile foundations of Team 1; *** has ** caps, ** piers, ** cap beams, and ** platforms for the lower structure of the ** bridge Hat, ** equipment: ** model crane **, formwork ** square meters, steel pipe support ** tons...

2. Bridge Pile Foundation and Substructure Team 2: The captain is **, the on-site technical person in charge **, and the on-site management personnel **. ***There are **pile foundations for **bridge, ***needs **drilling rig, **drilling rig has arrived, plans to arrive at **drilling rig on **month **, ***needs electricity **KW, temporary power consumption has been completed (or when it will be connected) **KW, self-provided generator set **, power **KW, it is estimated that each hole will take ** days, planned for October 30, 20xx Completed ** pile foundations, accounting for ** percentage of the total pile foundations of Team 2; *** has ** caps, ** piers, ** cap beams, and ** platforms for the lower structure of the ** bridge Hat, ** equipment: ** model crane **, formwork ** square meters, steel pipe support ** tons...

6. Construction arrangements for circular pipe culverts and cover passages

1. Circular pipe culvert: The leader of the first team is **, the technical person in charge is **, and the on-site construction personnel are named ** , *** needs to complete ** round pipe culverts, the existing equipment is **, and it is planned to complete 1 every ** day; the captain of the second team is **, the technical person in charge **, and the on-site construction personnel **, * **It is necessary to complete ** round pipe culverts, the existing equipment is **, and it is planned to complete 1 culvert every ** days.

2. Cover channel: The leader of the first team is **, the technical person in charge **, the name of the on-site construction personnel **, *** needs to complete the ** cover channel, and the existing steel formwork ** Square meters and ** tons of steel pipe supports, it is planned to complete 1 foundation every ** day and 1 wall every ** day; the captain of the second team is **, technical person in charge **, on-site construction personnel **, ** *It is necessary to complete the ** cover channel. The existing steel formwork is ** square meters and the steel pipe supports are ** tons. It is planned to complete 1 foundation every ** days and 1 wall every ** days;

….

7. Commitments on unfinished construction tasks

If the above commitments are not completed on time, I will voluntarily ask the legal representative of the unit **Month 20xx** Go to the Fuji Project Office and Section A Engineering Management Office on the same day to explain the reasons and make reasonable adjustments to the project management department’s organizational structure and construction organization design. If there is still no significant improvement on the site 20 days after the arrival of the legal representative, it has not been recognized by the supervision engineer. , I will request ** company headquarters to change the project manager and voluntarily leave Fuji Expressway on the grounds that I am not competent for my job.

Promisor: (Signature)

Certifier: Performance Commitment Part 3

In order to protect the legitimate rights and interests of migrant workers and not to default on their wages, I hereby declare ( The qualifications of the legal representative or authorized representative (name of the unit), solemnly promise:

The projects undertaken by our unit will ensure that:

1. Comply with the national regulations on project construction. , Consciously maintain and standardize the order of the construction market, be honest and abide by the law, employ and use migrant workers in accordance with the provisions of the Labor Law, and the wages will be paid directly to the migrant workers themselves. After receiving the project funds, the wages of the migrant workers will be paid first. Apply for work-related injury insurance for migrant workers when hiring and using them.

2. The projects undertaken shall not be subcontracted, illegally subcontracted or affiliated, and the illegal employment method of "contractor" style shall be eliminated.

3. If there is any violation of regulations in arrears or withholding of wages of migrant workers, resulting in petitions by migrant workers, or other emergencies or public incidents, our unit is willing to accept the punishment from the owner, and at the same time is willing to accept the instructions of the competent authorities in accordance with the regulations Other penalty decisions made by relevant regulations.

Committing unit: (official seal)

Legal representative or authorized agent (signature):

Date: Year, Month, Day Performance Commitment Letter 4

p>

Letter of Performance Commitment

Fuyang City Construction Committee:

If we win the bid organized by your center, we guarantee that after receiving the "Notice of Winning the Bid", Pay the bid winning deposit to your center's special account as required.

At the same time, in accordance with the requirements of the "Notice of Winning Bid", all responsibilities and obligations before signing the contract will be performed. Hereby pledge!

Bidder (official seal): Yangzhou Runguang Lighting Electric Co., Ltd.

Authorized person/agent (signature or seal):

Commitment date: 20xx May 18, 2018

Letter of Performance Commitment

Zhangqiu Municipal Government Procurement Center:

If we organize the construction of a new socialist countryside in Zhangqiu City at your office The street lamp project lighting equipment (No. ZQDL-20xx-008) won the bid. We guarantee that after receiving the "Notice of Winning the Bid", we will perform all responsibilities and obligations before signing the contract in accordance with the requirements of the "Notice of Winning the Bid".

If we breach the contract, we are willing to pay 30% of the amount involved in the breach as liquidated damages based on the breach notice issued by you within 5 days; we are willing to comply with the facts of the breach of contract. Handle opinions and ensure that you bear all consequences and responsibilities caused by your own breach of contract.

I hereby promise!

Bidder ((official seal): Yangzhou Xinghui Lighting Co., Ltd.

Authorized person/agent (signature or seal):

Telephone: 0514 -4213999

Fax: 0514-4216999

Commitment date: April 20, 2006 Performance Commitment Letter 5

My unit is in the project During the bidding, I was fortunate to win the bid. I am very grateful to the judges and the construction unit for their trust. During the implementation of the project, in addition to responding to all the terms in the bidding documents and fulfilling the contract content, we solemnly promise:

Here During the construction of the project, we must organize it carefully to ensure the construction period and quality, and ensure that we do not subcontract the winning project, and accept the supervision of the construction unit at any time.

If our unit is in the process of project implementation. If the company breaks its promise and violates regulations by subcontracting or subcontracting, it is willing to be punished by laws and regulations. It will bear the responsibility for the delay in project construction and quality problems caused by it, and will voluntarily withdraw from the site.

Commitment unit: (official seal)

Legal representative or authorized agent (signature):

Date: Year, month and day Performance Commitment Letter 6

p>

1. Our company’s quality goals: the first acceptance rate of projects reaches an advanced level; we strive to create famous brand projects every year and maintain certification levels in quality management.

2. Our company's quality policy: careful management, quality first, creating high quality, and customer satisfaction. This policy has clear logical relationships and clear direction goals, and determines the dynamic process. In summary, management is the means, supremacy is the purpose, quality is the effect, and satisfaction is This is the purpose.

3. This project meets excellent quality standards and cooperates with the main contractor to meet construction quality requirements. 4. Before construction, the construction staff will conduct a technical briefing and review the drawings. The entire construction process shall be carried out strictly in accordance with the drawings and specifications.

5. Establish a job responsibility system during construction, and conscientiously implement the three-level management system. Special work types must be certified and explained before work. Keep good records, strengthen the certification inspection process, implement mutual inspection, and promptly rework and correct any work that does not meet the requirements.

6. Do a good job in coordination among various types of work.

7. Make sure the measurement data and concealed acceptance records are completed, and the procedures are timely and accurate to create conditions for the completion acceptance.

8. The quality supervision department shall conduct regular inspections and supervision, and submit them to the quality supervision station for supervision. Ensure the smooth progress of construction quality.

9. Inspect and verify the warranty, certificate, material analysis, and technical data.

No installation will be allowed. p>

*************Company

Performance Commitment Letter of *******month****, ******Year 7

In the bidding activity of (Tender No.: ), if our company is lucky enough to win the bid, our company promises that the relevant taxes our company should pay will be withheld and paid to the Chaoyang City Taxation Department by the owner.

Name of the bidder (contractor):

Official seal:

Legal representative or authorized representative (signature):

Year and month Performance Commitment Letter Part 8

Performance Commitment Letter

To: Zhangtang Railway Project Management Department No. 2 District, China Railway 14th Bureau Group Co., Ltd.

We voluntarily Negotiate and agree with your organization (hereinafter referred to as "Party A") on the project construction labor cooperation within the Second Work Area of ??the Zhangtang Railway Project Management Department of China Railway 14th Bureau Group Co., Ltd., and make the following commitments.

1. Guarantee that the project undertaken will not be subcontracted or subcontracted. Otherwise, it will be treated as a breach of contract by us, and the performance bond paid by us can be confiscated as a fine.

2. Ensure to obey Party A’s leadership, dispatch and coordination, and handle the cooperative relationship with adjacent construction units. If due to changes in construction plans, construction period requirements, etc. or our reasons, we must obey Party A’s leadership, scheduling and coordination, and handle the cooperative relationship with adjacent construction units. adjustments made by the other side to our mission.

3. We promise that this project does not require advance payment. During the payment process of the project, if the owner cannot allocate funds to Party A on time, Party A’s allocation to us can be postponed equally. The appropriation is based on monthly work inspection and pricing. We provide the pricing information for the month in a timely manner and agree that the work inspection and pricing is for qualified and excellent projects. Payment is calculated based on the number of projects approved by Party A and does not exceed the construction drawing.

4. For every day the construction period is delayed, a penalty of 0.1‰ of the contract price will be imposed; if it exceeds 5 days, a penalty of 0.5‰ of the contract price will be imposed for every day the construction period is delayed; if it exceeds 10 days, Party A will have the right to terminate The contract will be settled based on the contract price minus 5% for the completed work.

5. During the execution of the contract, if we cannot guarantee the quality, safety, and progress, Party A has the right to unilaterally terminate the contract without any financial or legal responsibility; we guarantee that Party A will Evacuate the construction site within the specified time and compensate Party A accordingly for the losses caused.

6. Willing to sign a contract in the form of a comprehensive unit price contract negotiated by both parties, and guarantee that there will be no price adjustment during the execution of the contract.

7. Our project leader, technical leader, and mechanical equipment will arrive at the agreed time. If the project leader and technical director are delayed in entering the site, they will be punished for the delayed entry of the main equipment and key personnel, that is, each person will be fined 500 yuan per day. If the mechanical equipment is delayed, each machine will be fined 500 yuan per day. The amount of the fine will be deducted from the contract performance bond. The fine is only a means, but it does not exempt our personnel and machinery from the responsibility to continue to enter the site.

8. Our project leader guarantees to be at the construction site for a long time, and requests for leave must be reported to the person in charge of Party A’s construction site for approval. If he is not on site for no reason, he will be fined 500 yuan per day, which will be deducted from the personnel performance bond.

9. We guarantee to achieve the following points in terms of project quality:

⑴. The project quality complies with the construction specifications, procedures, quality standards and engineering construction standards issued by the Ministry of Railways. And accept the inspection by the construction unit and supervision engineer, and complete the concealed project visa procedures.

⑵. It must meet the technical requirements specified in the design drawing.

⑶. The quality standard of this project is the current Ministry of Railways Industry Excellent Engineering Standard, and the quality target is the Ministry of Railways Quality Project, striving for the National Excellence Award.

⑷. Project quality warranty and maintenance methods shall be handled in accordance with the industry regulations of the state and the Ministry of Railways.

⑸. Completion shall be accepted according to the acceptance standards issued by the ministry. The first pass rate of the unit project shall reach 100% and meet the requirements of the excellence planning of this construction project.

⑹. If the quality fails to meet the acceptance standards, all losses caused thereby will be borne by our unit.

10. We promise that for safety accidents caused by our own fault, we will bear all financial and legal responsibilities and properly handle the aftermath; we will never be responsible for improper handling of the aftermath of the accident. The situation that affects Party A. Otherwise, we will bear the economic losses and related legal liabilities caused to Party A due to improper handling.

11. During the execution of the contract, ensure that all work is carried out under the unified leadership of Party A, and that in business interactions with the owners, supervisors, bureau commanders, relevant local government departments and other supervisory units, the overall situation is taken into consideration Set out to actively maintain the credibility of the work area.

⑴. We have organized work classes and put them under Party A’s unified management; personnel are uniformly dressed according to Party A’s requirements, and machinery and equipment are uniformly labeled. Personnel shall receive education and training organized by Party A before taking up their posts. After passing the examination and obtaining certificates, personnel shall take up their posts with certificates.

⑵. All labor personnel shall sign labor contracts with us, register them in a register, prepare salary schedules on a monthly basis, and submit them to Party A for review; and ensure that under the supervision of Party A, all employees will work in accordance with the regulations of the local labor department and Party A requires timely payment of wages to migrant workers in accordance with the regulations on wage management of migrant workers; if any default in labor fees occurs, we promise that Party A has the right to terminate the labor contract and deduct the performance deposit and other payables paid by us as the payment of labor fees. And bear all economic losses and legal liabilities caused thereby.

⑶. We promise to bear all the risks of the floor materials and ancillary materials purchased by ourselves. We guarantee that after the completion of the project, no disputes arising from the materials purchased by us will affect Party A. Any economic and legal responsibilities arising from the flooring materials and other small materials, machinery, etc. purchased by the other party shall be borne by us.

12. We agree that all main materials and special materials (including but not limited to concrete, cement, sand, gravel, steel bars, concrete additives, rubble, steel strands, anchors, corrugated pipes) Party A will organize unified bidding and procurement. Suppliers of self-purchased materials must be approved by Party A. Party A has the right to designate suppliers when necessary.

13. During the construction process, our consumption of materials provided by Party A shall not exceed the material consumption limit.

If it exceeds the consumption limit, we promise that the excess material consumption will be A Party B will deduct the price of the market price × 110 from Party B’s current settlement price.

14. We are willing to unconditionally obey Party A’s construction environmental protection, soil and water conservation measures; occupational health and safety measures; labor organization plan; civilized construction, cultural relic protection and a series of measures that are beneficial to the project.

15. If we fail to achieve the phased construction period target or fail to meet the quality standards as required by Party A, Party A has the right to adjust our project scope and quantity, and has the right to replace the construction labor team. We guarantee to evacuate the construction site on time, and all our temporary equipment or mechanical equipment will be provided to Party A free of charge until the project is completed and returned without any payment.

16. We understand the lack of funds allocated by the owner, the impact of land acquisition and demolition, and the delay in providing design change documents, and promise not to affect the progress and quality of the project.

17. We promise that once the contract is signed, the comprehensive unit price will not be adjusted. If a loss occurs, we will bear it ourselves, and we only need to keep a copy of the construction project work content in the construction labor contract; due to the second We promise to consider compensation for lost work due to delays caused by three parties after the construction unit approves Party A’s compensation fee, and it will not exceed the construction unit’s approval fee. If the construction unit does not approve, no compensation is required; the cost of changes during construction Increase, we promise to consider compensation only after the construction unit approves Party A's change fee, and it will not exceed the construction unit's approved fee. If the construction unit does not approve the change fee, no compensation is required.

18. We guarantee that during the construction process, none of our personnel will cause any trouble, make trouble, or block the project department, mixing station, Party A’s vehicles and personnel in Party A’s work area. Otherwise, , Party A has the right to immediately terminate the contract, and even submit the construction contract to the court where the legal person agency of Party A is located for prosecution. At the same time, we bear all economic and legal responsibilities and guarantee to vacate the site within 24 hours.

19. During the performance of the contract, we guarantee that no personal abuse, insult, personal attack, or other infringing and offensive behavior will be carried out against Party A’s staff at any time and in any place. If there is a conflict due to our reasons, Party A will refuse to have any contact with our work and confiscate the performance guarantee deposit paid by it. If the case is serious, the public security and judicial authorities where Legal Person's agency is located will make a decision.

20. This letter of commitment is one of the main contents of the signed "Engineering Construction Labor Service Cooperation Contract".

Pledger:

Performance Commitment Letter 20xx Year Month Day 9

1.3 Bid Security Deposit

Proof of Bid Security Deposit (Paste Copy of bid deposit receipt)

1.4 Project-related commitment letter

1.4.1 Commitment letter not to replace the project manager and technical person in charge;

1.4.2 Letter of commitment from the project manager and technical person in charge;

1.4.3 Letter of commitment from other project team managers;

1.4.4 Commitment to ensure no subcontracting or illegal subcontracting Letter;

1.4.5 Letter of commitment on quality, construction period, safety and civilized construction;

1.4.6 Letter of commitment guaranteeing not to borrow qualifications;

1.4 .7 Letter of commitment to ensure no bid-rigging or collusion in bidding;

1.4.8 Letter of commitment to performance;

1.6.9 General contracting management, coordination and cooperation for professional projects Service Commitment Letter.

1.4.1. Letter of commitment not to change the project manager and technical director

To: (Tenderer)

As a bidder for the project, once you win the bid , we solemnly promise:

1. The project manager and technical person in charge will not be replaced during the execution of the project contract. The project manager and main technical person in charge are only responsible for the construction tasks of this project; such as our company In case of breach of contract, the tenderer has the right to terminate the contract and confiscate the performance bond

2. If the project manager or technical director needs to be replaced due to special reasons, our company will report it in writing 14 days in advance. After soliciting the tender After the person agrees and records it with the Ezhou Municipal Tendering Supervision and Administration Bureau, the successor will continue to exercise the predecessor's rights as stipulated in the contract documents and perform the predecessor's obligations.

3. Our company promises that even with the consent of the tenderer and the Ezhou Municipal Tendering Supervision and Administration Bureau, this behavior will still be regarded as a breach of contract by our company. If the project manager is replaced, the liquidated damages shall be paid at the rate of 1% of the winning bid price; if the technical person in charge is replaced, the liquidated damages shall be paid at the rate of 0.5% of the winning bid price.

4. If the tenderer believes that there are members of the contractor's management team who are not qualified for the corresponding positions, it may require the winning bidder (contractor) to replace and adjust them until they are satisfied, and pay liquidated damages at 0.5 of the winning bid price.

Bidder (seal):

Legal representative (signature):

Year, month and day

1.4.2. Project Letter of commitment from the manager and technical person in charge;

To: (Tenderer)

As a project bidder, once we win the bid, we solemnly promise:

1. During the execution of the project contract, the project manager and technical director are present and strictly accept the owner's attendance system and leave system. The project manager and technical person in charge must be on duty for no less than 80% of the construction time of the month each month, and the working time on the job must not be less than 6 hours per working day;

2. The project manager and technical person in charge do have special needs If it is necessary to take leave and leave the site, if the time is less than half a day, the written consent of the supervisory director must be obtained; if the time is more than half a day and less than two days, the written opinion must be issued by the supervisory director, and must be reported to the representative of the contractor for approval and reported to the Ezhou Municipal Tendering Supervision and Administration Bureau. Filing. Before leaving, a temporary representative should be designated in writing to exercise his/her authority; all actions of the temporary representative will be considered by the contractor to be the actions of the project manager or technical person in charge.

3. The project manager and technical director shall not leave their posts without obtaining written consent in accordance with the above provisions. Otherwise, liquidated damages of 10,000 yuan will be paid for one resignation; liquidated damages of 20,000 yuan will be paid for the second resignation. ; Liquidated damages of RMB 50,000 will be paid for each subsequent payment after the third time. If the total number of absences (absences, departures) exceeds 10 times or the cumulative annual leave exceeds 20 days, it will be treated as a breach of contract, except that the contractor (winning bidder) will pay the breach of contract. In addition to fines and fines, the contractor will be removed from the contract in accordance with regulations, a record of bad behavior will be recorded, and the Ezhou Municipal Bidding Supervision and Administration Bureau will impose a 6-month to 3-year qualification restriction on the contractor's bidding in Ezhou City, depending on the circumstances.

Bidder (seal):

Legal representative (signature):

Year, month and day

1.4.3 Project team Letter of commitment from other management personnel;

To: (Tenderer)

As a bidder of the project, once we win the bid, we solemnly promise:

Except for the project manager , the technical person in charge is in place as promised in the bidding document, our company will not send personnel other than the project team and other management personnel promised in the bidding document to participate in the management of this project. Otherwise, our company will be deemed to have breached the contract, and the tenderer has the right to terminate the contract and confiscate the performance of the contract. Security deposit. At the same time, the contractor shall report to the Ezhou Municipal Bidding Supervision and Administration Bureau. The Ezhou Municipal Tendering Supervision and Administration Bureau will grant the contractor a qualification limit of 6 months to 3 years to bid in Ezhou City.

Bidder (seal):

Legal representative (signature):

Year, month and day

1.4.4. Guarantee Letter of commitment not to subcontract or illegally subcontract

To: (Tenderer)

As a project bidder, once we win the bid, we solemnly promise: During the execution process, we will never subcontract or subcontract illegally. If there is subcontracting or illegal subcontracting, our company is willing to accept the following penalties:

1. The tenderer shall report to the municipal, provincial and national construction and other administrative departments and make a bad record;

2. During the performance of the contract, the contractor has the right to order him to appear, and the tenderer has the right to terminate the contract and confiscate the performance bond.

3. The tenderer shall contact the judicial authorities to pursue relevant legal responsibilities.

Bidder (seal):

Legal representative (signature):

Year, month, day