Current location - Trademark Inquiry Complete Network - Trademark inquiry - Product advertising design and production contract
Product advertising design and production contract

At present, with the rapid development of social economy and information technology, the number of advertising production companies and the amount of business undertaken have greatly increased compared with a few years ago. So what should we pay attention to when signing an advertising production contract? I have compiled the "product advertising design and production contract" for reference only, hoping to help everyone! Product advertising design and production contract 1

Party A: (hereinafter referred to as "Party A")

Party B: (hereinafter referred to as "Party B")

In view of the needs of Party A's product sales, Party B has the ability and legal qualification to produce advertising materials under this contract (hereinafter referred to as "advertising materials"), and Party A entrusts Party B to produce advertising materials under this contract.

1. Production items and contents of advertising materials (exhibition boards, exhibition stands, integrated exhibition stands, box stickers and color pages):

2. Production requirements and delivery of advertising materials:

1. Party A is responsible for providing Party B with the design draft (see Annex 1), and Party B shall make it strictly in accordance with this design draft, and in [] [ Otherwise, Party A has the right to require it to rework, and the expenses incurred shall be borne by Party B..

2. party b shall use its own equipment, technology and labor to complete the production of advertising materials in this contract. without the written consent of party a, party b shall not hand over the production of advertising materials in this contract to a third party. Otherwise, Party A has the right to terminate the Contract at any time without any responsibility.

3. Party B shall complete the production of all advertising materials and deliver them to the delivery place designated by Party A on [] of []: (Instructions for Use ①). Transportation expenses and risks shall be borne by Party B.. Party B shall properly package the advertisement according to its nature, so as to make it suitable for long-distance transportation.

4. Party A shall check and accept the advertisement according to the contract, the design draft and the samples confirmed in advance, and if it is qualified, Party A shall issue a written acceptance form, which shall be deemed as the completion of delivery by Party B; The unqualified products shall be replaced by Party B within 5 days, and the expenses incurred shall be borne by Party B..

5. The ownership of the advertising material shall be transferred from Party B to Party A at the delivery place when Party A passes the acceptance.

party b shall bear all or part of the loss, damage and other losses of the advertising materials before they pass the acceptance; Party A shall bear the above losses after the acceptance.

iii. rights and obligations of party a:

1. party a is responsible for providing the design draft.

2. Party A has the right to supervise the production progress and quality, and put forward suggestions for improvement.

3. Party A shall pay Party B the required funds on time in strict accordance with the contract payment period.

IV. Rights and obligations of Party B:

1. Party B shall submit the business certificate and corresponding qualification documents to Party A for Party A's inspection and filing;

2. Party B shall provide a detailed quotation list, provide a reasonable quotation to Party A, and propose a preferential scheme for Party A;

3. Party B shall process and make advertising materials in strict accordance with the design draft provided by Party A; If Party B fails to make the confirmed design draft and causes losses to Party A, or fails to finish it on time, which causes delay in Party A's use, Party A may deduct money or postpone payment according to the seriousness of the case, and the specific method shall be subject to Party A's written notice;

4. Party B is responsible for the regulation of the whole design and production project;

5. Party B has the right to obtain relevant information of each specific project. Party B shall have strict confidentiality obligations for all kinds of materials obtained from Party A, including but not limited to design samples and related logo words. If Party B discloses it without authorization, and Party A suffers losses as a result, Party B shall make compensation.

V. Price and payment method:

1. Total contract cost: RMB. Yuan (including tax)

(in words: RMB only). Besides, Party A has no further payment obligation.

2. payment method and time: payment shall be made within [] months after all the advertisements are accepted by Party A.. Party B shall, within 1 day after acceptance, provide Party A with the legal and valid invoice of the total contract amount and the accounting confirmation letter specified in Article 9 (Annex 2), otherwise Party A has the right to refuse payment.

VI. Intellectual property rights

1. Any documents or other materials provided by Party A that have been used up must be returned by Party B to Party A after the execution of the contract and before Party A pays, and no copies are allowed. And delete the relevant information stored in Party B's computer. Otherwise, Party A has the right to make absolute payment.

2. Party A has complete intellectual property rights over Party A's trademarks and design drafts provided by Party A, and Party B can only use Party A's trademarks and advertising design drafts on Party A's advertising materials. Party B shall not use Party A's trademark and design draft for purposes other than this contract or provide it (intentionally or unintentionally) to a third party. Once Party A is found, Party A has the right to hold Party B accountable and demand Party B to compensate all (direct and indirect) losses suffered by Party A as a result.

3. Party A owns all intellectual property rights, including copyright, for the draft scheme under this contract from the beginning. Party B shall not use these design drafts for other purposes or provide them (intentionally or unintentionally) to a third party, otherwise Party A shall have the right to investigate Party B's tort liability once found.

VII. Liability and compensation for breach of contract

1. If either party violates the provisions of this contract, the other party has the right to demand correction or dissolution of this contract, and to demand compensation for all economic losses.

2. except for force majeure, party b shall deliver the samples and final advertising materials according to the time required by party a. if party b fails to deliver them on time (including replacement within a time limit), party b shall pay a penalty equivalent to 1% of the total contract price to party a for each day of delay. The liquidated damages shall be calculated from the second day of the delivery date stipulated in this agreement to the actual delivery date of Party B.. If Party B delays delivery (including replacement within a time limit) for more than 1 days, Party A has the right to terminate the contract, and Party B shall pay Party A a penalty equivalent to 2% of the total contract amount. If Party A suffers actual losses due to Party B's delayed delivery, Party B shall also bear corresponding compensation responsibilities.

3. Party A shall pay Party B on time, and if Party A delays payment, it shall pay Party B two ten thousandths of the delayed payment amount as liquidated damages. The liquidated damages shall be calculated from the second day of the payment deadline stipulated in this agreement to the actual payment date of Party A.. However, if Party A delays payment due to Party B's failure to provide the payment materials agreed in this contract, it will not bear the liability for breach of contract.

4. if party b's production work is suspected of violating the law or infringing the legitimate rights and interests of a third party, party b shall bear all the responsibilities arising therefrom, including but not limited to compensation for the losses caused to party a ..

5. The liquidated damages that have been determined will not be affected by the termination of the contract and the assumption of the liability for compensation for losses.

VIII. Force Majeure

If this contract cannot be performed due to force majeure, the party suffering from force majeure shall notify the other party as soon as possible after the occurrence of force majeure and take reasonable measures to prevent the loss from expanding. Neither party shall be liable for the failure to perform due to force majeure. How to continue to perform the contract shall be settled by both parties through consultation.

the party unable to perform the contractual obligations due to force majeure shall notify the other party of the occurrence and termination of the force majeure that hinders the performance of the obligations as soon as possible, and provide the necessary supporting documents, and shall put forward the handling opinions in the notice. If the other party is damaged due to the failure to notify in time, it shall be liable for compensation.

IX. Pre-accounting check

1. Within one week after signing this contract, Party B shall check the existing accounts with Party A or its branches before signing this contract. If there are unsettled accounts between Party B and Party A or Party A's branches before signing this contract, Party B shall issue an account confirmation letter (in duplicate) to Party A within one week after signing this contract, and attach the expense details, which shall be signed and sealed by Party A after review to confirm the existing accounts. Party A and Party B each hold one copy of the confirmation letter of accounts. The unsettled account confirmed by the account confirmation letter shall be paid in the way specified in the contract signed between Party B and Party A or Party A's branch at the time of this account occurrence or otherwise determined in the account confirmation letter.

2. This account confirmation letter is an effective annex to this contract (Annex 2).

X. Law Application and Dispute Resolution

1. The conclusion, validity, interpretation, execution, modification, termination and dispute resolution of this contract shall be governed by the laws of China and China.

2. Any disputes and disputes arising from the performance of this contract between Party A and Party B shall be settled through negotiation as far as possible; If negotiation fails, either party has the right to bring a lawsuit to the people's court where Party A is located, and the judgment result is legally binding on both parties.

Xi. Other

1. Other matters not covered shall be settled by both parties through consultation.

2. without the written consent of both parties, neither party may modify this contract.

3. The authorized representatives of both parties have obtained the legal and effective authority to sign this contract, and this contract will come into effect after being signed and stamped by the authorized representatives of both parties. The validity period is until the date when the rights and obligations of both parties under this agreement are fulfilled. After the termination of the contract or the completion of performance, the provisions on confidentiality and intellectual property rights shall remain valid.

4. this contract is made in duplicate, each party holds one copy, which has the same legal effect.

5. the annexes and supplementary agreements of this contract are an integral part of this contract and have the same legal effect as this contract. In case of any inconsistency between the annex and this contract, this contract shall prevail.

Party A: Party B:

Representative:

Date: Date: Product Advertising Design and Production Contract II

Entrusting Party: (hereinafter referred to as Party A)

Producer: (hereinafter referred to as Party B)

According to the relevant provisions of the Economic Contract Law of the People's Republic of China, Party A and Party B

commissioned production method:

according to the requirements put forward by party a, party b will send technicians to guide, install and conduct civilized construction on site.

2. Price and amount of commissioned production:

1. Total amount of the agreement: RMB

2. Quantity of the agreement: time of commissioned production:

from year month day to year month day.

iii. Production acceptance:

Party B shall deliver it to Party A for acceptance after production.

after the extension, the materials shall be dismantled and recycled by party b.

IV. Payment method of production funds:

When signing the contract, Party A shall pay 5% of Party B's total amount, that is, 25% in words, that is, RMB, in words:

V. Safety responsibilities

All safety accidents caused during the installation and construction of this contract shall be borne by Party B..

VI. Liability for breach of contract

If Party B fails to complete the project within the time limit, it will be a breach of contract, and the breaching party shall pay 3% of the total liquidated damages to the observant party on a daily basis. If Party A fails to pay in advance, Party A shall pay Party B a late fee of 3% per day according to the actual number of days in arrears and the total amount in arrears.

VII. Supplementary Provisions

1. This contract shall come into effect after being signed and sealed by both parties;

2. the supplementary agreement has the same effect as this contract;

3. this contract is made in duplicate, all of which have the same legal effect.

party a (official seal): _ _ _ _ _ _ _ party b (official seal): _ _ _ _ _ _

legal representative (signature): _ _ _ _ _ _ _ _ legal representative (signature): _ _ _ _ _ _ _ _ _. :

Entrusted party (Party B):

In accordance with the Contract Law of the People's Republic of China and relevant laws and regulations, and on the principle of mutual benefit and good faith, Party A's xxxxx Products Co., Ltd. entrusts Party B's xxxxX Advertising Co., Ltd. to be responsible for the production and installation of the rooftop advertisement at No.98, North of xx Village, xx Town, XXXX District, and hereby signs this contract.

article 1: advertising specifications, materials and prices:

article 2: procurement, completion period and quality of raw materials:

1. party b is responsible for the procurement of raw materials, and must select raw materials in accordance with the contract and accept inspection. When Party B uses raw materials that do not meet the requirements of the contract, which affects the quality of customization, Party A has the right to request redone. Redo materials and the price shall be borne by Party B..

ii. production completion date: 31, 2xx.

iii. the production quality has reached the standard agreed in this contract, and Party A shall check and accept it.

article 3. design adjustment during the performance of the contract: during the work according to the requirements of party a, if party b finds that the drawings or technical requirements provided are unreasonable, it shall notify party a in time; Party A shall reply within the specified time and propose amendments. If Party B fails to get a reply within the specified time, it has the right to stop working and notify Party A in time, and Party A shall compensate for the losses caused thereby.

article 4. approval of advertising procedures: party b is responsible for the approval of outdoor advertising procedures, including urban comprehensive law enforcement departments, industrial and commercial administrative departments, planning departments, fire departments, meteorological departments, etc., and all departments related to this outdoor advertising publicity apply for approval procedures. The expenses involved shall be borne by Party B. After completing the approval procedures, Party B shall submit a copy of the procedures to Party A..

article 5, acceptance criteria and methods:

1. take the contract materials, drawings and samples as the acceptance criteria.

ii. all accidents caused by unreasonable design, unstable installation and inadequate maintenance of outdoor advertising installation project shall be borne by party b.

Article 6. Settlement method of the contract price:

After Party B completes the manufacturing and installation works, all the money will be paid in one lump sum within 5 working days after Party A's acceptance, and Party B will provide the completed photos and customer confirmation form, and the acceptance form and invoice will be delivered to Party A..

Article 7. Liability for breach of contract:

1. If Party A agrees to make use of the customized product or the work not according to the quality stipulated in the contract, the remuneration or price shall be reduced according to the quality; Do not agree to use, should be responsible for repair or replacement, and bear the responsibility of overdue delivery; If it still does not meet the contract requirements after repair or replacement, Party A has the right to reject it, and Party B shall compensate for the losses caused thereby.

2. if the quantity of customized products delivered or work completed is less than the contract, if Party A still needs it, it shall make it up according to the quantity, and the overdue part shall be treated as overdue delivery; Party B shall compensate Party A for the losses caused by the short or late delivery that Party A no longer needs.

iii. after the signing of the cooperation agreement by both parties, if Party B fails to complete the advertising and publicity work according to the time required by the agreement, Party A will be fined 1% of the total amount of this agreement for each day of delay.

iv. after party a and party b signed the cooperation agreement, the contents produced and installed by party b failed to meet the requirements of the agreement.