Complete works contract agreement 1
Party A:
Party B:
In accordance with the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, in order to clarify the rights, obligations and responsibilities of Party A and Party B in this project contracting, and ensure that the project task is fully completed according to the design quality requirements, both parties sign this contract through consultation on the principle of voluntariness, equality and mutual benefit.
Article 1 General situation of the project
(1) Project name:
(2) Project location:
(3) Project scope:
(4) Project contract amount: the amount calculated by the Employer according to the unit price agreed by both parties, and the unmeasurable items shall be settled by the daywork. (unit price of mortar rubble: Yuan /M3, unit price of concrete: /M3)
Article 2 The construction period shall be determined by both parties through consultation. The construction period starts from the date of month to the date of month. If the project task is not completed on schedule, RMB will be deducted.
Article 3 Project Quality Party B shall carry out the construction according to the drawings provided by Party A and relevant national quality standards to ensure the project quality. When the project is accepted, it shall be implemented according to the drawings and acceptance standards.
Article 4 After the project payment settlement project comes into play, 60% of the project payment shall be paid according to the construction progress of completed quantities; When the project is completed, Party B shall issue a Jian 'an invoice to pay 90% of the total project amount; The remaining 10% is used as the project quality deposit and is under construction.
After delivery and acceptance, the balance will be paid in one lump sum.
Article 5 responsibilities of both parties
(I) Party A's responsibilities
1. Party A shall provide information such as construction drawings, and Party B shall carry out the construction in strict accordance with the design drawings.
2. The materials provided by Party A shall be within the construction scope of Party B's tower crane, and the expenses shall be borne by Party A if the second transshipment is needed.
3. Party A shall send representatives to the site for technical guidance, quality supervision, inspection and quality inspection.
4. After the completion of the project, Party A will organize a special person to conduct acceptance on 30th.
5. The project scope shall be borne by Party A. ..
(II) Party B's responsibilities
1. All personnel entering Party B's site must obey the management and arrangement of Party A, carry out the construction work in strict accordance with the safety construction specifications and quality acceptance specifications, and make relevant materials.
2. In the process of construction, Party B shall formulate safety measures to strengthen the safety education and management of on-site construction personnel. In case of safety accident, all responsibilities shall be borne by Party B..
3. The mixture ratio of concrete and mortar shall be provided by Party A, and Party B shall not be responsible for the failure to reach the strength, and Party B shall be responsible for the quality accidents caused by the construction. Party B shall save materials on the premise of ensuring quality. If Party B is found to waste materials intentionally, Party A has the right to impose a fine of 3-5 times according to the seriousness of the case (such as adjusting the mixture ratio without authorization, collecting materials scattered on the ground, etc.). ).
Article 6 Liability for breach of contract
1. If it fails to meet the quality requirements, it shall not only bear the rework losses, but also bear the shutdown expenses, water, electricity and building materials expenses caused to Party A ... (The expenses for making materials shall be borne by Party A).
2. Party A has the right to impose a fine on 200 yuan according to the seriousness of the case if it fails to construct according to the safety operation rules and does not obey the command of the on-site management personnel.
3. If the construction task cannot be completed according to the contract time limit and the project schedule issued by Party A, Party A has the right to impose a fine on 200 yuan for each day of delay, in addition to compensating the direct losses (salary of management personnel, equipment rent and turnover materials) caused to Party A..
4. If Party B wastes materials due to poor management in the construction process, if Party A finds that the concrete or mortar blocks exceed 100Kg, it has the right to impose a fine on 200 yuan.
Article 7 If Party B subcontracts this contract without authorization, it will unconditionally deduct 10000 yuan from the completed engineering quantity of Party B as liquidated damages and pay it to Party A, and bear the economic losses caused to Party A therefrom, and terminate this contract at the same time.
Article 8 For other matters not covered, Party A and Party B shall negotiate separately. If there is any dispute about this contract, they can apply for arbitration.
Article 9 This contract shall come into force as of the date of signature by both parties, and shall automatically become invalid after the project is completed and accepted and the balance of the project is settled. This contract is made in duplicate, one for each party.
Representative of Party A: Representative of Party B:
Company Tax Number: Company Tax Number:
Bank of deposit: Bank of deposit:
Account number: Account number:
Telephone fax: Telephone fax:
Project contracting agreement daquan ii
Employer: (Party A)
Contractor: (Party B)
I. Project name:
Two. Scope of contract: all construction contents of the project.
Third, the way of contracting: contracting for labor and materials
Four. Commencement and Completion Time: Commencement Time Month Day Completion Time: Year Month Day.
Five, quality requirements:
Acceptance standard of intransitive verbs: according to the current corresponding engineering construction specifications, the acceptance of both parties shall prevail.
7. Warranty date: one year, counting from the date of completion acceptance.
Eight. Responsibilities of both parties:
Party A:
1, responsible for providing water and electricity within 50 meters of the site.
2, responsible for timely disbursement of project funds according to the image progress.
3. Be responsible for ensuring that the site meets the construction requirements.
4, responsible for the coordination work in engineering construction, etc.
Party B:
1, responsible for the safety of construction personnel, and all economic losses due to unsafe accidents caused by illegal construction.
2, do a good job in project management, construction process, all the current relevant specifications, to ensure the time limit for a project, to ensure the engineering quality requirements.
3. Take good care of Party A's original facilities and compensate the losses according to the price.
Nine, the settlement method:
1. The settlement of this project shall be carried out in accordance with Zibo Price List and Consumption Quota of Installation (Construction) Project in Shandong Province.
2. Construction enterprises charge according to three categories.
3, the construction unit pricing, pricing and settlement.
4. Contract pricing part:
X. Allocation method:
1, the project starts at% of the budget;
2, after the completion of the project acceptance, according to% of the budget;
3. After the project is completed and accepted, after the settlement is completed,% of the settlement amount will be allocated, and the balance will be paid within one year (within one month).
1 1. Disputes between the two parties: in case of disputes, arbitration shall be conducted by the statutory arbitration department of Zibo.
This contract is made in duplicate, which shall come into effect after being signed by both parties, and shall become invalid after the project payment is paid.
Employer: (Representative of Party A)
Contractor: (Party B) Representative
date month year
Project contracting agreement daquan 3
Party A: (Lessor) _ _ _ _ _ _ _ _ _ _ Village Committee of Lijiashan Town
Party B: _ _ _ _ villagers
In order to make full use of land resources, do a good job in three-dimensional high-yield breeding, and better implement the vegetable basket project, according to the Contract Law of People's Republic of China (PRC) and relevant regulations, the rights and interests of Party A and Party B are clearly defined, and this contract is signed by both parties through coordination.
Rule number one. Leased Property Party A will contract the Dawan Bay floodplain in _ _ _ _ village to Party B to build a breeding base. This plot is located in _ _ _ _ _ _ _ _ village of Lijiashan Village, with a land area of 15 mu.
Article 2. Lease Term The lease term is _ _ _ _ _ _ _ _ years.
Article 3. The rent and the time for paying the rent are RMB five thousand yuan only (5,000 yuan) per year, and the time for paying the rent is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 4. During the lease period, the right to use and profit from the leased property belongs to Party B, and Party A no longer has the right to use and profit.
Article 5. Changes between Party A and Party B
1. During the lease term, if Party A transfers the ownership of the leased property to
The third party (including expropriation) must obtain the consent of Party B, otherwise it may not sublet or transfer.
2. Party B contracts to lease the house for other reasons.
The third party must obtain the consent of Party A in advance.
Article 5. Land expiration and expropriation agreement
1. During the lease period, if Party B expropriates the lessor (that is, land) according to law, the lessor may be exempted from paying rent after the expiration of the expropriation period of Party B.. The land expropriation right and related income shall be owned by Party A. ..
2. During the lease period, if Party B fails to requisition the property of Party A, this contract shall be re-signed three months before the specified lease expires. If both parties are willing to extend the lease term, if Party B no longer uses Party A's property, the fixed assets invested by Party B shall be settled through negotiation.
Article 6. responsibility for breach of contract
1. During the lease period, Party A has no right to interfere with Party B, and Party B shall not change other properties of the land (aquaculture only) except for the above circumstances.
2. During the lease term, if Party B fails to pay the rent on time, Party A may charge a late fee of 3% per month.
Article 8. Ways to resolve contract disputes Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, a lawsuit may be brought to the people's court.
Article 9. Other agreed matters During the lease term, Party B has no right to transfer the leased property (i.e. land) to a third party.
Article 10 Supplementary Agreement If Party B fails to put into production during the lease period and the land is abandoned or closed for more than _ _ _ _ _ _ _ _, Party A has the right to terminate the agreement and recover the land use right.
Article 11 Matters not covered in this contract shall be supplemented by both parties through consultation in accordance with the relevant provisions of the Contract Law, and the supplementary provisions shall have the same legal effect as this contract.
Article 12 Party B shall pay the management fee of Wu Bai Yuan (500 yuan) to the villagers committee every year.
Article 13 This contract is made in duplicate, with each party holding one copy.
Party A (Lessor):
Party B (lessee):
Legal representative:
Legal representative:
Complete works contract agreement 4
Party A: _ _ _ (specify name, legal representative and address) (employer)
Party B: _ _ _ _ (same as above)
(Contractor)
Party A and Party B have reached the following agreement in accordance with the principles stipulated in the Economic Contract Law of the People's Republic of China and the Regulations on Construction Project Contracts and in combination with the actual situation of this project.
first
General situation of contracted projects (including project name, location, content, contract scope, commencement and completion date, quality grade, etc.). )
second
Language, standards and applicable laws used in the contract documents (this article is mainly used for foreign-related aspects)
essay
Drawings (indicating date, number of sets, confidentiality requirements, drawings description, etc.). ).
Article 4
On-site representatives of Party A and Party B (indicate name, gender, age and position in the unit)
Article 5 Basic work of both parties
Article 6
Project progress plan
Article 7 Project supervision (including intermediate acceptance of concealed works, etc.). )
Article 8 The price of personnel contract and its adjustment
Article 9
Payment method and time of project advance payment and project price
Article 10 Project acceptance
Article 11 Final accounts
Article 12
Ensure to keep in good condition or repair.
Article 13 Dispute settlement
Article 14 Liability for breach of contract
Article 15 Other contents agreed by both parties.
Article 16
This contract is made in duplicate, with each party holding one copy. This contract will come into effect on _ _ _ _ (indicate the effective time or conditions). For matters not covered in this contract, both parties may sign a supplementary agreement through consultation. The supplementary agreement has the same effect as this contract.
Packaging issuer
Name of unit (seal):
Unit address:
Legal representative:
Entrusted agent:
Telephone message:
Telegraph registration:
Bank of deposit:
Account number:
Postal code:
date month year
contractor
Name of unit (seal):
Unit address:
Legal representative:
Entrusted agent:
Telephone message:
Telegraph registration:
Bank of deposit:
Account number:
Postal code:
date month year
Evaluation (public) certification opinion
Handler:
Forensic (public) certification body
(Seal)
date month year
[Note: Unless otherwise stipulated by the state, the appraisal (certification) is voluntary. ]
explain
A construction project contract is a contract with the construction project as the target, including a construction project contract, a construction project survey contract and a construction project design contract. The construction project contract is a very complicated contract. It involves engineering technical standards, quality supervision and inspection, construction period and other issues, as well as many laws and regulations.
Therefore, the conclusion of the construction project contract should be stipulated according to different situations, so as to be accurate, clear and correct and ensure the smooth progress of the project. In particular, the technical terms and meanings of different projects are often different. Therefore, when concluding a contract, it is more necessary to clarify the applicable laws and technical standards and their meanings.
Generally speaking, we should pay attention to the following three aspects:
(1) As a contractor, we must first understand the basic situation of the project, including the drawings, quantities, project difficulty, construction period and construction intensity to be achieved provided by the employer. If the contractor's construction strength is not suitable for the project, it should be clear, otherwise it should bear corresponding responsibilities.
(2) As the employer, review the qualification level of the contractor and whether it has the strength to contract the project.
Whether the contractor is allowed to subcontract shall be clearly stated in the contract in advance.
(3) The Employer shall strengthen the supervision and inspection of the project quality, and specify the way, time and project content of supervision in the contract; Appropriate arrangements should be made for the parts that need intermediate acceptance.
Project contract agreement daquan 5
Both parties to the contract:
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
The contractor _ _ _ _ _ _, hereinafter referred to as Party B.
In order to implement the contract responsibility system of joint production, fully mobilize the production enthusiasm of members, and clarify the rights and obligations of both parties, this contract is hereby concluded with the consent of the general meeting of members and full consultation of both parties, in accordance with the spirit of the central documents (83) and (84) 1, so that both parties can abide by it jointly.
1. Area, location and grade of contracted land
Party A has contracted out _ _ _ _ mu of land (field) to Party B, which one is located in _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Second, the contract time.
The contract period is * * _ _ years, starting from _ _ _ _ _ _ _ _.
_ _ _ _ _ _ _ _ _ _ _ _ _.
Three. Rights and obligations of Party B
Party B has the right to obtain agricultural materials such as fertilizers, pesticides, improved varieties and loan indicators allocated by the state for the development of agricultural production.
3. Party B must complete the planting plan issued by the superior, and can decide the planting operation independently on the premise of completing the planting plan.
13. Party B must complete the task of allocating the unified purchase index and paying the agricultural tax per mu, and sell _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. Pay the agricultural tax of _ _ _ _ _ yuan to the state every year, and the tax payment time is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. Party B must pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ USD to Party A. Party B must complete the voluntary working days allocated by Party A according to the mu of contracted land, or pay a discount amount according to the voluntary working days.
(This article may also take the form of a list, see below).
3. With the consent of Party A, Party B may subcontract the land by itself and negotiate with the subcontractor to purchase the grain for daily use at a low price. After the land is subcontracted, the subcontractor must undertake all the tasks originally undertaken by Party B, and pay the "three funds" to Party A and complete the tasks of compulsory labor.
5. If Party B is born (not in violation of family planning regulations), dies, gets married or gets married, the contracted place will generally remain unchanged, but its obligations must be adjusted according to regulations. If Party B can't continue to contract the land due to the reduction of labor force, and no one is willing to transfer the contracted land, it can propose to Party A to return part or all of the contracted land, and Party A will make unified arrangements separately. Party B's obligations to the state and the collective shall be reduced or exempted accordingly.
Party B has the responsibility to protect the trees, irrigation, drainage, power supply and other national or collective facilities on the contracted land.
Four. Rights and obligations of Party A
1. Party A has the right to supervise Party B to complete the planting plan, unified purchase task and tax payment task assigned by the state, and has the right to urge Party B to fulfill its obligations to the collective.
3. The state allocates agricultural materials such as fertilizers, pesticides, improved varieties and loan indicators for agricultural production as planned, and Party A timely distributes them to Party B according to the quantity and grade of contracted land.
3. Party A shall regularly publish the collective financial accounts and the use of provident fund, public welfare fund and management fee, and must accept the supervision and inspection of Party B. ..
Verb (abbreviation of verb) liability for breach of contract
1. If Party B fails to fulfill its obligations to the state and the collective on time, it shall pay liquidated damages to Party A at _ _% of the delayed project value in addition to continuing to perform. If Party B still refuses to perform its obligations, Party A may request relevant information.
In addition to handling, this department has the right to recover the land contracted by Party B..
If Party B wastes the contracted land, Party A has the right to recover the land in addition to fulfilling all obligations to the state and the collective. If Party B sells or leases the contracted land without authorization, Party A may declare the relationship between sale and lease invalid and recover the land. If Party B builds a house on the contracted land, Party A has the right to order Party B to demolish it. If Party B destroys trees and collective facilities on the contracted land, it shall pay compensation according to the price (the damaged trees shall be discounted).
3. If Party A fails to timely allocate to Party B the agricultural materials such as chemical fertilizers, pesticides, improved varieties and loan indicators allocated by the state, it shall pay liquidated damages to Party B at _ _ _% of its value, and reissue the owed materials in full.
Force majeure of intransitive verbs
If crops in the contracted land are reduced or not harvested due to natural disasters of force majeure, Party B may reduce or exempt its obligations to the state or the collective according to the actual situation after investigation and verification.
Seven. others
____________________________________________________________________ ________。
This contract shall come into effect from the date of commencement of the contract period. During the contract period, if the head of the household dies, his family members have the right to contract for inheritance. This contract shall not be changed due to the change of Party A's representative. During the execution of the contract, neither party may change or terminate the contract without authorization; If there are any matters not covered in this contract, Party A and Party B shall make supplementary provisions through consultation.
Supplementary terms have the same effect as this contract.
The original of this contract is in duplicate, one for each party; A copy of this contract exists in the form of _ _ _ _ _ _ _ _ _
Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Representative: _ _ _ _ _ _ (seal)
Head of household of Party B: _ _ _ _ _ _ (seal)
Completed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Related articles in the encyclopedia of engineering contract agreement;
★ Simple engineering contract 10
★ 3 Model project contract and agreement.
★6 concise versions of the latest project contract agreement.
★ Collection of model project contract agreement
★ 3. Simple version of the project contracting agreement.
★ The latest three simple project contracting agreements
★ 10 construction project contract
★ General five contracts for simple projects
★ Project contract agreement template
★ The latest project contract agreement