Central Air Conditioning Installation Contract 1 Party A:
Party B:
According to the relevant provisions of the Economic Contract Law of the People's Republic of China, Party A and Party B have reached an equipment installation contract through friendly negotiation, the contents of which are as follows:
I. Overview of the Project:
Project Name: Installation and Commissioning of Central Air Conditioning System
Project location:
Two. Scope of contract:
Scope of contract: installation, commissioning, acceptance and maintenance of central air conditioning system engineering.
Party B shall provide brand-new and unused installation equipment and materials, technical services and other necessary matters. During the performance of the contract, if Party B fails to provide or meet the technical performance indicators in the design drawings, Party B shall take remedial measures free of charge and bear all responsibilities. For the technical requirements required by Party A but not put forward in the contract documents, Party A has the right to issue a change notice, and Party B has the responsibility to meet Party A's change requirements with reasonable progress and the most favorable price.
The bidding documents and bidding documents, as annexes to the contract, constitute an integral part of this contract, and both parties promise and abide by it.
Third, the contract cost:
The total cost of this contract is RMB.
RMB in words: RMB only.
3. 1 "contract price" refers to the central air-conditioning system project of this project, in addition to the central air-conditioning system equipment provided by Party A (see the attached table for the equipment provided by Party A), from the installation equipment and
RMB quotation for materials, installation and debugging, spare parts supply until completion acceptance, delivery and maintenance. , including the cost of materials, packaging, transportation and miscellaneous fees, loading and unloading fees, installation fees, commissioning fees, spare parts supply fees, all fees until the acceptance and delivery, maintenance fees during the maintenance period, etc.
3.2 The contract price is fixed, including all the extra expenses caused by the fluctuation of raw material prices or other conditions, except the price adjustment caused by Party A's increase or decrease of engineering quantity.
3.3 The contract price includes the cost of all special tools, tests, instruments and consumables related to the contract provided by Party B during the equipment installation and commissioning, and Party B is responsible for transporting them into and out of the project site.
3.4 The contract price includes all transportation and accommodation expenses for Party B's personnel to the site. Party A shall assist Party B's personnel to live conveniently on site, but the relevant expenses shall be borne by Party B. ..
3.5 Unless otherwise specified, Party B's price shall include the implementation and completion of the work described in the contract documents and all indispensable incidental work and expenses, whether these work and expenses are specified in the contract documents or not, and whether they can be foreseen when signing the contract.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Central air conditioning installation contract II Party A (the buyer):
Contact telephone number:
Party B (supplier and installer):
Contact telephone number:
According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B have reached the following agreement on the installation of central air-conditioning equipment by Party B on the basis of equality and voluntariness:
Article 1 Party A's orders, equipment specifications, models, quantities and project overview:
1. Equipment conditions (see quotation sheet for details):
2, the installation project overview:
Project location:
Start date: XX (Year, Month and Day)
Completion date: XX (year, month and day)
Article 2 When Party B's engineering materials enter the site, Party A shall confirm and designate the place where the goods are stacked (the place designated by Party A must be secured), and both parties shall be responsible for the safety of the engineering materials.
Article 3 Installation, debugging and acceptance of products:
1. Party B is responsible for the installation and commissioning of central air-conditioning equipment.
2. The installation quality standard shall meet the national standards and industry requirements, as well as the engineering installation design instructions provided by Party B and the manufacturer. Party B shall notify Party A of the acceptance on the day when the project is completed, and Party A shall organize personnel to accept the project within three days after receiving the acceptance notice. If the quality and content of the project meet the requirements, the representatives of both parties shall sign and seal the project acceptance form (form). The product installation scheme shall be based on the design drawings and selection scheme proposed by Party B and agreed by Party A; If it is necessary to change the design scheme, it must be agreed by both parties through consultation; If the aircraft type adjustment is involved, it shall be confirmed by both parties through consultation.
Article 4 Payment method:
1, and the contract price is the contract project payment+negotiation price of both parties;
2. The total project price of this contract is RMB (in words: RMB only).
3. When signing this contract, Party A shall pay Party B a deposit of RMB.
In words: Yuan (accounting for 30% of the total project price);
4. Party A shall pay Party B RMB (in words: 60% of the total project price) for the second phase of the project after Party B's engineering materials and equipment enter the site for acceptance and signature;
5. After the equipment debugging is completed and the project is completed and accepted (subject to the date of the acceptance report), pay off the remaining amount. The ownership of materials and air conditioning equipment shall be owned by Party B before Party A pays the full amount; Party B informs Party A of the acceptance, and if Party A fails to participate in the acceptance without reason within one week, it will be deemed as qualified.
6. The above price excludes residential property management fee, drilling fee for special drilling rig and equipment hoisting fee.
Article 5 responsibilities of both parties
I. Party B's responsibilities:
1. The person in charge of Party B at the project site is fully responsible for the installation and construction site;
2. Except for negotiation, if Party B delays delivery, it shall pay liquidated damages to Party A, but the total amount of liquidated damages shall not exceed 20% of the total price. If Party B still fails to deliver the work after reaching this deadline, Party A may consider terminating the contract, and the losses caused to Party A therefrom shall be borne by Party B, unless it is signed and approved by Party A. ..
3. If Party B delays the construction period without reason, it shall pay a penalty of 1‰ to Party A for each day of delay, except for Party A's reasons. ..
Two. Party A's responsibilities:
1. The person in charge of the construction site of Party A is fully responsible for the coordination and cooperation of the installation construction site;
2. Party A is responsible for laying the power supply for indoor and outdoor units of air conditioner and building the base of outdoor unit.
3. Party A shall be responsible for the water and electricity expenses during the construction period and assist in handling the entry and exit certificates of Party B's construction personnel.
4. If Party A terminates the project halfway, Party A shall pay Party B a penalty of 50% of the contract price.
5. If Party A fails to pay the project payment within the time stipulated in the contract, Party A shall pay Party B a penalty of 1‰ of the total contract amount for each day overdue, but the total penalty shall not exceed 20% of the total contract amount. If Party A still fails to pay after reaching this limit, Party B has the right to terminate the contract and take back the central air-conditioning equipment and auxiliary materials within one month. Party A shall bear the economic losses of Party B, and Party B may also pursue Party A's relevant legal responsibilities. ..
6. If Party A needs to adjust the product model, it shall notify Party B in time, and bear Party B's repeated transportation, storage, equipment price difference, material loss and other related expenses.
7. If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after confirmation by both parties:
(1) engineering quantity change or design change;
(2) Force majeure;
(3) Work stoppage caused by Party A's failure to pay on time and participating in stage acceptance;
(4) Other circumstances in which Party A agrees to postpone the construction period.
Article 6 Product quality responsibility and after-sales service clauses
1. The project warranty period is one and a half years from the date of acceptance (i.e. 18 months).
Due to product quality problems outside the warranty period, Party B will charge basic maintenance fees. If damaged parts are replaced, Party B will charge fees according to the ex-factory price of the replaced parts.
2. After the warranty period ends, Party B shall provide lifelong paid maintenance service for air conditioner users. The content and mode of service shall be separately signed by the user and Party B voluntarily.
Article 7 If this contract cannot be performed normally due to force majeure, both parties shall settle it through friendly negotiation.
Article 8 Ways to settle contract disputes: Any dispute arising from the execution of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, either party may bring a lawsuit to the people's court where the plaintiff is located according to law.
Article 9 This contract shall come into effect as of the date of signature and seal by both parties.
Article 10 The design drawings and quotation scheme specifications of this project submitted by Party B and confirmed by Party A are annexes to this contract.
Article 11 If there are matters not covered in this contract, both parties can make supplementary provisions through consultation, which have the same effect as this contract.
Article 12 The original of this contract is in duplicate, with each party holding one copy.
Article 13 The annex to this contract is an integral part of this contract and has the same legal effect as this contract.
Party A: Party B:
Agent:
Tel: Tel:
Date: Date:
Central Air Conditioning Installation Contract 3 Party A: Tel:
Party B: Tel:
According to the relevant provisions of the Contract Law, Party A and Party B have reached the following terms through friendly negotiation.
I. Installation Project: Central Air Conditioning Equipment
1, installation location:
2. Building structure:
3. Installation content and price (see the construction drawings and quotations confirmed by both parties)
Second, the installation time and warranty period:
1. installation time: indoor decoration shall be carried out in a synchronous and coordinated manner, and the modification or progress of Party A's decoration project shall not be affected by improper time.
2. Warranty period: free warranty for five years after installation and commissioning, and lifelong maintenance.
Third, the central air conditioning brand and total price
1. Installation brand: See the installation quotation of central air conditioning equipment for the material requirements of Gree B series ancillary facilities.
2. Installation price:
This price is the final price to ensure the normal operation of the air conditioner.
Four. Payment method:
Verb (abbreviation of verb) installation requirements:
1. Specific installation location: the location and wiring of air vents shall be carried out according to the construction drawings confirmed by both parties. If Party A needs to make temporary changes, both parties will negotiate separately.
2. The air-conditioning brand installed by Party B must adopt materials consistent with the brand, specification, model, quality and measurement standard in the quotation, and conform to various national safety regulations and industry norms.
Six, installation acceptance:
1. The installation and construction drawings confirmed by both parties shall prevail. If there is any change, both parties shall negotiate.
2. Brand, material and model. The use is consistent with the quotation details, and the use effect reaches all the indicators in the manual.
Seven. Liability for breach of contract:
1. Party B's installation time must be coordinated with Party A's renovation progress, which will affect Party A's renovation progress and bear Party A's corresponding delay losses. ..
2. In case of overdue payment, Party A shall pay Party B two thousandths of the total project price every day.
3. If Party B uses fake or inferior brands and materials in the installation, Party A has the right to order Party B to dismantle and replace them until they meet the requirements, and bear the corresponding losses.
4. In case of quality problems during the trial period, Party B shall bear the losses caused to Party A's decoration.
Eight. Matters not covered in this contract shall be settled by both parties through consultation. This contract is made in triplicate, one for each party and one for the manufacturer, and shall come into effect after being signed by both parties.
Nine, the two sides have objections or disputes due to the quality or the effect of cooling and heating, which shall be resolved through the appraisal standards of authoritative departments.
Party A: Party B:
Legal representative:
Agent:
Tel: Tel:
Fax: Fax:
Date: Date:
Central Air Conditioning Installation Contract 4 Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, on the basis of equality, voluntariness and friendly negotiation, both parties reached the following agreement on the installation and procurement of central air-conditioning project of Zhuxi County Power Supply Bureau:
1. Project scope: procurement, construction, installation and commissioning of central air-conditioning equipment in Zhuxi Power Supply Bureau.
2. Engineering requirements: According to the requirements of the central air-conditioning installation contract signed by Party A and the owner, the central air-conditioning and terminal system configuration are installed in place according to the determined design scheme.
Third, the project cost and payment:
1. The total cost of this project is RMB: the above price does not include the use fees of the main engine foundation, main engine power supply and main pipeline steel frame.
2. Within three days after the signing of this agreement, Party A shall pay all the project funds to Party B, and Party B shall enter the site for construction.
3. Party B's bank account:
Fourth, the project quality:
1. Party B must carry out the construction in strict accordance with the construction progress required by Party A. If Party A suffers losses due to late delivery, Party B shall bear all the losses.
2. The materials used by Party B must meet the national standards, and each batch of installation materials must be accepted by Party A's technicians. Party A has the right to require Party B to replace the unqualified materials, and Party B shall bear the losses caused by the project delay. ..
3. Party B must carry out the construction according to the installation specifications and process requirements. During the installation, Party A's technicians have the right to check the installation quality and process. If it does not meet the requirements, Party B must make rectification unconditionally and bear all losses such as delay.
Five, equipment and engineering quotation sheet
Six, after-sales commitment
1. system warranty: the warranty period of the installation project is 2 years, and the warranty start time is calculated from the date of project completion and acceptance. During the warranty period, if there is any fault due to the installation quality, Party B shall repair it for free. Party B will not undertake free maintenance due to the failure caused by Party A's improper operation or equipment operation environment. After the warranty period. Party A and Party B can negotiate maintenance matters separately.
2. The equipment shall be guaranteed for two years from the date of delivery. If the equipment fails due to Party A's improper operation or equipment operation environment, Party B will not undertake free maintenance. After the warranty period. Party A and Party B can negotiate maintenance matters separately.
Seven. Matters not covered in this contract shall be settled by both parties through consultation. If negotiation fails, it may be submitted to the local people's court for settlement.
Eight. This contract is made in quadruplicate, with each party holding two copies. It will take effect after being signed and sealed by both parties!
Party A, Party B, legal representative, legal representative, entrusted agent and entrusted agent:
Date of signature: year month day.
Central air conditioning installation contract 5 Party A:
Party B:
According to the relevant provisions of the Economic Contract Law and the Construction and Installation Project Contract, and in combination with the situation of this project, the following agreement is reached through careful negotiation between both parties:
I. Overview of the Project
1, project name:
2. Project location:
3, equipment supply and supply contract scope
(1) This contract includes the supply, installation and commissioning of the central air conditioning system in the supermarket. See air conditioning design drawings.
(2) Installation contents include fan coil installation, outdoor host installation, pipeline connection, pipeline insulation and system debugging.
(3) The concrete foundation of the outdoor unit of the air conditioner shall be manufactured by Party A in advance according to the dimensional parameters provided by Party B. ..
(4) Party A shall lay the power supply of the outdoor unit and the indoor unit in place, Party B shall be responsible for leaving holes in the beams through which the air conditioning pipes pass, Party A shall be responsible for the repair work, Party A shall be responsible for laying the control ducts, and Party B shall be responsible for the connection of the power cord with the outdoor unit and the indoor unit.
4. Construction period: According to the requirements of Party A and the actual situation on site, the construction period is set at 30 days, subject to the date when Party B enters the site. In case of the following circumstances, the construction period will be postponed.
(1) Delayed disbursement of project funds.
(2) Cross-operation and technical visa delay.
(3) irresistible.
(4) The construction period is delayed due to reasons other than Party B's.
5. Project quality: Construction and acceptance according to GB——50243.
Contract price
1, air conditioning equipment and installation
Serial number, name, model, specification, quantity, unit price and price remarks
1 Installation fee table of refrigeration host and accessories
2 Installation fee table of fan coil unit and accessories
total
2. Terms of payment
(1) Payment method for air conditioning equipment
Within three days after the signing of the contract, Party A shall pay 30% of the total cost as the advance payment for the project.
B pay 40% of the total cost when the goods arrive at the construction site.
C. 20% shall be paid within ten days after the installation is completed and accepted.
Pay 95% of the contract after completing a cooling-off season. (Keep 5% quality deposit)
① The remaining 5% shall be paid within seven days after the expiration of two years.
(2) In case of equipment and engineering changes, the construction representative of Party A may issue a change order for equipment and engineering to Party B, and sign a change agreement as an annex to this contract, which has the same legal effect as this contract.
Third, the completion acceptance:
1, completion acceptance and intermediate acceptance shall be based on the agreement of both parties, design and construction drawings, relevant change visas and relevant construction specifications.
2. Party A shall complete the intermediate acceptance and examination and approval of other construction documents within two days after Party B submits the materials or reports, and assist Party B to complete them together, so as not to affect the subsequent projects. If it is overdue, it means that Party A agrees.
Fourth, the warranty:
1. Party B shall guarantee the equipment and works within its supply and construction scope for two years free of charge.
2. The warranty period is calculated from the date when the installation and commissioning are qualified.
Verb (short for verb) Responsibility of both parties:
1, Party A's responsibility
(1) Party A shall ensure that the construction site has the construction conditions, ensure the water circuit tee, and provide the warehouse. The public facilities shall be undertaken by Party B, and Party A shall cooperate with Party B in the construction.
(2) Appoint Party A as the on-site representative, and notify Party B in writing two days in advance if there is any change.
(3) The on-site representative of Party A has the responsibility to coordinate the on-site crossover operation and other work matters.
2. Party B's responsibilities
(1) Provide brand-new equipment according to the technical requirements of the contract, and ensure that all parts of the equipment have good performance and meet the technical standards.
(2) Party B shall change the on-site visa according to the construction drawings and relevant regulations, and complete the construction content on schedule with good quality and quantity.
(3) If Party B is appointed as the on-site representative, it shall notify Party A in writing two days in advance if there is any change.
(4) Party B shall obey the reasonable work arrangement of Party A. ..
Other intransitive verbs:
1. In case of any dispute, both parties shall settle it through friendly negotiation. The negotiation results are attached to the contract in the form of "minutes" and have the same effect as the contract. If negotiation fails, it shall be handled in accordance with the relevant provisions of the Economic Contract Law.
2. Liability for breach of contract and losses shall be calculated according to actual losses.
3. The construction drawings, changes and other technical documents related to this contract approved by Party A have the same legal effect as this contract.
4. As an annex to the contract, the tender has the same legal effect.
Seven. This contract is made in sextuplicate, and Party A keeps four copies. Party B shall keep two copies.
Party A (seal): Party B (seal): Party A's representative: Party B's representative:
Telephone: electricity
Words:
Fax: Fax:
Employer of Central Air Conditioning Installation Contract 6: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)
Tel: _ _ _ _ _ _ _ _ _ _ _ _ Address: _ _ _ _ _ _ _ _ _ _ _ _ _ Representative of Party A: _ _ _ _ _ _ _ _ _ _ _ _ _
Contractor: _ _ _ _ _ _ (hereinafter referred to as Party B)
Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B have reached the following agreement on the installation of central air-conditioning equipment by Party B on the basis of equality and voluntariness:
Article 1 Specification, model, quantity and general situation of the equipment ordered by Party A and installed by Party B:
1, equipment:
Product name, specification, model and unit quantity
2, the installation project overview:
(1) Project location and area:
(2) Project cost: ￥;
(3) Commencement date: YY MM DD YY 20xx years;
(4) Completion date: 20xx years;
(5) Payment methods: (1), cash (2) and transfer check.
Article 2 When Party B's engineering materials enter the site, Party A shall confirm and designate the place where the goods are stacked (the place designated by Party A must be secured), and both parties shall be responsible for the safety of the engineering materials. After Party B installed and debugged the central air conditioner, Party A has passed the site acceptance and signed the acceptance; Materials and equipment shall not be used or installed without the acceptance and signature of both parties.
Article 3 Installation, debugging and acceptance of products:
1. Party B is responsible for the installation and commissioning of central air-conditioning equipment.
Party A and Party B agree that:
Before (1) and (20xx), Party B shall send engineering and construction personnel to the site to start the installation;
(20xx years ago, completed the construction and acceptance of the previous concealed works;
(Equipment installation and system debugging were completed 20xx years ago. The completion acceptance of all central air-conditioning projects should be carried out at the same time as the completion of decoration. All required materials should be in place at the time agreed by both parties.
2. The installation quality standard shall meet the national standards and industry requirements, as well as the engineering installation design instructions provided by Party B and the manufacturer. Party B shall notify Party A of the acceptance on the day when the project is completed, and Party A shall organize personnel to accept the project within three days after receiving the acceptance notice. If the quality and content of the project meet the requirements, the representatives of both parties shall sign and seal the project acceptance form (form). Party B is responsible for providing product certificate, material certificate, product warranty, daily operation procedure description and fault consultation. The product installation scheme shall be based on the design drawings and selection scheme proposed by Party B and agreed by Party A; If it is necessary to change the design scheme, it must be agreed by both parties through consultation; If the aircraft type adjustment is involved, the supplementary text of the contract shall be signed for confirmation.
Article 4 Method and time limit of price settlement:
1. The contract price is the payment method (fixed price) of the installation project agreed by both parties;
2. The total installation price of this contract is RMB: _ _ _ _ _ _ _ _ _ _ _ _ (in words);
(1) After the contract is signed, Party A shall pay Party B RMB (50% of the total contract amount) _ _ _ _ _ _ _ _ _ _ _ (in words:);
(2) After Party B's engineering materials (non-finished products) enter the site, Party A will pay Party B (Phase II project payment) RMB (accounting for _ 47 _ _% of the total contract amount) _ _ _ _ _ _ _ _ _ _ _ _ _ (in words:) within three days;
(3) The balance of the project (accounting for __3_% of the total contract amount) is RMB (in words: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _), which shall be paid by Party A within three days after the equipment debugging is completed and the project is completed and accepted. Before Party A pays the full amount, the ownership of materials and air conditioning equipment belongs to Party B. ..
3. The above price excludes residential property management fee, drilling fee for special drilling rig and equipment hoisting fee.
Article 5 Liability for breach of contract
I. Party B's responsibilities:
1. The person in charge of Party B at the project site is fully responsible for the installation and construction site;
2. Unless otherwise stipulated in the contract, if Party B fails to deliver the work within the time stipulated in the contract, Party B shall pay a penalty of 1‰ of the total price to Party A for each day overdue, but the total penalty shall not exceed 20% of the total price. If Party B still fails to deliver the work after reaching this deadline, Party A may consider terminating the contract, and the losses caused to Party A therefrom shall be borne by Party B, unless it is signed and approved by Party A. ..
3. If Party B delays the construction period without reason, it shall pay Party A a penalty of 1‰ for each day of delay, but
Except for Party A's reasons. ..
4. Party B shall be responsible for the responsibilities and losses caused by unqualified installation.
Two. Party A's responsibilities:
1. The person in charge of the construction site of Party A is fully responsible for the installation construction site;
2. Party A shall create conditions for Party B to enter the site for construction, vacate the site and connect the water and electricity for construction _ _ _ days before commencement;
3. Party A shall provide Party B with the confirmed design scheme and installation and construction list _ _ _ days before the commencement of construction;
4. If Party A terminates the project halfway, Party A shall pay Party B a penalty of 50% of the contract price.
5. If Party A fails to pay the project payment within the time stipulated in the contract, Party A shall pay Party B a penalty of 1‰ of the total contract amount for each day overdue, but the total penalty shall not exceed 20% of the total contract amount. If Party A fails to pay after reaching this limit, Party B has the right to terminate the contract and take back the central air-conditioning equipment. Party A shall bear the economic losses of Party B, and Party B may also hold Party A accountable.
5. If Party A needs to adjust the product model, it shall notify Party B in time, and bear Party B's repeated transportation, storage, equipment price difference, material loss and other related expenses.
6. If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after confirmation by both parties:
(1) engineering quantity change or design change;
(2) Force majeure;
(3) Work stoppage caused by Party A's failure to pay on time and participating in stage acceptance;
(4) Other circumstances in which Party A agrees to postpone the construction period.
Article 6 Product quality responsibility and after-sales service clauses
1. The warranty period of the project is one year from the date of acceptance (provided by Da Lin Refrigeration).
Due to product quality problems outside the warranty period, Party B will charge basic maintenance fees. If damaged parts are replaced, Party B will charge fees according to the ex-factory price of the replaced parts.
2. After the warranty period ends, Party B shall provide lifelong paid maintenance service for air conditioner users. The content and mode of service shall be separately signed by the user and Party B voluntarily.
Article 7 If this contract cannot be performed normally due to force majeure, both parties shall settle it through friendly negotiation.
Article 8 Ways to settle contract disputes: Any dispute arising from the execution of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, either party may bring a lawsuit to the people's court where the plaintiff is located according to law.
Article 9 This contract shall come into effect as of the date of signature and seal by both parties.
Article 10 The design drawings, quotation specifications and other documents of this project submitted by Party B and confirmed by Party A.
This is an annex to this contract.
Article 11 If there are matters not covered in this contract, both parties can make supplementary provisions through consultation, which have the same effect as this contract.
Article 12 The original of this contract is in duplicate, with each party holding one copy.
Article 13 The annex to this contract is an integral part of this contract and has the same legal effect as this contract. Annex to the contract:
Employer (Party A): Contractor (Party B):
Address: Address:
Postal code:
Representative: representative:
Telephone: telephone
Fax: Fax: