Part 1: Elevator installation contract agreement

In order to strengthen management, adapt to the current market economy, implement the principle of distribution according to work, fully mobilize the enthusiasm of installation personnel, and further improve the efficiency of installation personnel To ensure the quality of installation and better serve users, the elevator installation is contracted and a contracting agreement is specially formulated. This agreement applies to passenger elevators, sightseeing elevators, patient elevators, escalators, and freight elevators.

1. Installers work as a team and bundle quality, construction period, safety, wages, bonuses, travel and accommodation expenses, tools, materials and various subsidies into a single unit contract.

2. Elevator installation project details:

Site name: Jiangxia Lighting City Contract number: Elevator type and specification model Kangli KLM Quantity 2 units Contracting fee: 8,000 yuan ?1 unit; the total price is in capital letters: ?Ten thousand and six thousand yuan

3. Contracting fee and settlement method

1. This installation contracting fee includes; all tools used in the construction and All labor costs, accommodation fees, transportation fees, communication fees, temporary shaft lighting, cutting blades, welding rods, oxygen used in construction, acetylene, toothless saw blades, and all steel wires used for laying out wires.

2 Within 3 days after the installer enters the site, the company will pay the installer the elevator installation contract fee (30% of the total installation contract price)

3 The elevator installation must be accepted by the national quality inspection department. After handing over for maintenance, those that do not require acceptance need to be confirmed by the company after debugging and no need for rectification. The company then pays the installer the elevator installation contract fee (60% of the total installation contract price)

4 After the company's maintenance department officially accepts and confirms the tailless project, the company then pays the installer the elevator installation contract fee ( 10% of the total installation contract fee). Otherwise, the company will not settle the entire installation contract fee.

IV. Installation date

From the time when you can enter the installation site, the installation time is: year month day to ? Installation, date not included.

5. The company’s responsibilities and rights

1. Assess the quality and operating skills of the installation personnel. Those who do not meet the requirements may be disqualified from installation at any time. The installer must comply with all provisions of this contract.

2. Provide the installers with the "Elevator Installation Acceptance Construction Record" and "Elevator Installation Acceptance Self-inspection Record" necessary to ensure the quality of elevator installation.

3. Responsible for the debugging and inspection of elevators

4. Have the right to inspect and verify various processes at the construction site at any time in accordance with national standards.

5. The company regularly inspects and supervises the safety protection of on-site workers and safety protection supplies.

6. Have the right to supervise the contractor (actor) on the payment of wages to the contractor (actor)’s subordinates.

VI. Responsibilities and authority of the installation personnel

1. Before contracting the elevator installation, the installer must sign an elevator installation contracting agreement with the company before they can implement the elevator installation project.

2. According to the requirements of the agreement, the installers must firmly establish the idea of ??"safety first, quality first" and adhere to the principle of combining on-site "self-inspection" and "mutual inspection" to ensure that the installation and construction site Construction quality.

3. The unpacking and inventory work before installation must be completed within 7 days. Once errors or missing parts are found, the "Elevator Unpacking Inspection Record Form" must be truthfully filled in and reported to the company in a timely manner. The company will not be responsible after 7 days. , all errors and missing parts are your own responsibility. The parts that have been checked and confirmed must be carefully kept. Damage or loss will be the responsibility of the installer and compensation will be based on the price.

4. The rectification suggestions put forward by the inspector must be carefully rectified to ensure quality.

5. The installer’s self-inspection during installation should be strictly carried out in accordance with the inspection standards specified by the company, and the company’s inspections should be accepted at any time.

6. The installer discovered quality problems during the installation process. The "Quality Feedback Form" should be filled in and fed back to the company in a timely manner.

If on-site changes are required, they should be made with the company's consent.

7. Unlicensed personnel are strictly prohibited from entering the site for work, and temporary workers are not allowed to be hired without permission. Temporary laborers are not allowed to enter the shaft or work at high altitudes. The laborers are only responsible for transportation and must be over 22 years old and under 45 years old. The contractor (team representative) should regularly provide safety education to team members before and after work at any time and at any time. The contractor (actor) is fully responsible for site safety. The contractor (leader) shall be responsible for any personal injury or death accidents.

8. The contractor (leader) is responsible for the installation workers’ accident insurance, social insurance, labor protection, operation certificate and other expenses.

VII. Elevator installation quality assurance and verification methods

Part 2: Elevator installation contract

Party A:

Party B:

p>

In accordance with the provisions of the "Contract Law of the People's Republic of China" and relevant laws and regulations, after negotiation between Party A and Party B on the basis of friendly will, equality and mutual benefit, both parties voluntarily reached the following agreement regarding the installation of the project elevator, Both parties must abide by it.

1. Project Overview:

1. Project Name:

2. Project Location:

3. The elevator installed by Party B is ?The elevators involved in the "Elevator Equipment Purchase Contract" signed between Party A and the company on the day of the year.

2. Installation scope

1. Installation of elevator machine room equipment (installation materials other than the machine room power supply gate box)

2. Installation of related equipment in the shaft (Materials and installation of elevator shaft lighting system)

3. Installation and commissioning of the entire elevator equipment and installation of shaft steel structure and glass curtain

4. Waiting hall included in the contract Installation of equipment related to the elevator

5. Installation of wire troughs in the machine room and shaft and laying of wires and cables

6. Assembly of counterweight and car and hanging of traction ropes Equipment

7. Installation of lighting equipment in the hoistway and pit

8. Installation of machine room, pit electrical maintenance box and pit ladder

9. Installation Debugging and trial operation after completion

10. Party B is responsible for providing all materials, accessories and tools required for installation except the overall elevator package.

11. Party B shall be responsible for all installation and debugging work, except for the above, to ensure that the elevator provided by Party A meets the normal operation and passes the inspection and acceptance of both parties.

3. Contract price

1. Installation fee price

The number of installations in this contract is tentatively determined to be ? units, and the purchaser temporarily needs to install ? elevators. The number of elevators to be installed under the contract is tentatively determined to be ?, and each installation department will be given a complimentary installation of one elevator. The standards of the complimentary installed elevators should be consistent with that elevator, and the provisions of this contract shall apply.

The equipment transportation fee per unit in this contract is: (RMB) lowercase yuan

(RMB) uppercase yuan

The installation and commissioning fee per unit in this contract is : (RMB) lowercase? Yuan

(RMB) uppercase? Yuan

Note: The unit price is guaranteed and will be settled based on the actual transportation and installation volume.

2. This contract price includes all costs required for installation, transportation, debugging, storage, testing, acceptance by both parties, taxes, etc. of the elevator, as well as maintenance and upkeep during the maintenance period.

IV. Payment method

1. The transportation fee for the equipment in the current order confirmation order shall be paid in full to the account designated by Party B ten working days before shipment.

2. The contract is signed and takes effect. Party A shall pay Party B 50% of the current installation contract price within 3 working days after Party B enters the site;

3. All elevators under this contract have been installed. , and within ten working days after passing the acceptance of both parties, Party A will pay Party B 47% of the current contract price;

4. The remaining balance is the warranty deposit, which will be refunded without interest if there are no quality problems after the one-year warranty period. .

5. Before Party A pays Party B, Party B must issue a formal invoice to Party A for the full price of this contract, otherwise Party A has the right to refuse payment.

6. If the elevator requires mandatory inspection by the relevant departments of Hebei Province and the Special Equipment Supervision and Inspection Institute, Party B will bear the inspection fee.

7. Payment terms for the installation of sample ladders: The installation price of the sample ladder shall be paid to the supplier in full at one time within ten days after the supplier and the buyer accept the ladder in accordance with the unit price agreed in this contract. There is no prepayment for the installation of the sample ladder. payment.

8. No invoice will be issued for the free elevator installation fee.

V. Construction Period

The elevator installation period under this contract is 90 days/90 units. The specific start time shall be subject to Party A’s written notification.

VI. Installation and acceptance

1. Party B must comply with the design requirements of the drawings and elevator installation requirements, instructions and current elevator equipment installation and inspection in accordance with the regulations of the People's Republic of China and the People's Republic of China. Standards, in accordance with or higher than GB10060-1993 "Elevator Installation and Acceptance Code" GB7588-2003 "Elevator Manufacturing and Installation Safety Code" GB16899-1997 "Escalator and Moving Walkway Manufacturing and Installation Safety Code" GB50310-2002 "Elevator Engineering Construction Quality Manufactured and produced according to the national standard "Acceptance Specifications", and installed according to the requirements of the installation specifications. Party B is responsible for handling the registration procedures for the start of construction, and is responsible for the installation, commissioning, and trial operation of all elevators until they pass the acceptance of both parties. (If testing and acceptance by relevant departments at the location of the project is required and relevant procedures must be obtained).

2. After signing the contract, Party B is responsible for sending personnel to the site to conduct civil engineering surveys and perform corresponding operations to ensure that the project site meets the installation requirements and conditions.

3. Party B must take various safety measures and protection measures during the entire construction process. All costs incurred in the event of personal injury or safety accidents shall be borne by the responsible party and have nothing to do with Party A.

4. Party B is responsible for the safety and custody of the elevator equipment during the installation period.

5. Party A is responsible for coordinating the general contracting management fees incurred with the general contractor during the installation. Party B is responsible for the special expenses such as scaffolding in the elevator shaft and water and electricity fees used for elevator installation.

6. Party B shall ensure safe and civilized construction on site and clean-up of garbage, comply with various management regulations and requirements of Party A’s project site, and cooperate with other construction units in accordance with Party A’s requirements, and obey the project Unified command and coordination on site. Anyone who disobeys relevant management will be cleared from the scene.

7. Party B must promptly inspect the relevant materials and accessories provided by itself. Materials and accessories that have not been inspected by the supervision unit and Party A shall not be used. However, such inspection and acceptance will not exempt Party B from liability for inherent quality defects in the materials and accessories it supplies.

8. After Party B completes the installation and debugging and meets the acceptance conditions, it shall submit an acceptance application to the supervision unit and Party A as required, and Party A and Party B will accept the acceptance in both directions.

VII. Information

1. Within 3 days after signing the contract and entering the site, Party B shall promptly submit the formal relevant construction organization, plans, programs, safety assurance measures, etc. to the supervision unit or Party A. Documents are reviewed and filed.

2. Party B must promptly submit relevant certification documents and information for the relevant materials and accessories provided by itself.

3. Provide relevant technical documents and other information and certificates in accordance with relevant national regulations.

8. Warranty and maintenance

1. Party B promises to maintain and maintain all elevators under this contract free of charge for one year (the elevators installed by Party B shall be stored for no more than 1 year from the date of delivery). 18 months). According to national regulations, the monthly maintenance frequency is 2 times. Carry out system maintenance and inspection on the elevator every quarter, every six months, and every year (see the attachment for maintenance content). During the maintenance period, Party B will be responsible for the replacement of the host machine and components due to quality problems in the elevator itself.

2. During the maintenance period, Party B must arrange a sufficient number of personnel to carry out daily maintenance and meet the relevant maintenance standards. And maintenance personnel may not be replaced at will without Party A's consent.

3. Party B shall complete the training of Party A’s personnel according to the time specified by Party A, and cooperate with Party A free of charge in handling procedures such as bidding filing, completion acceptance, etc. as required.

4. In addition to the above, Party B shall provide after-sales services in accordance with the commitments in its bidding documents.

5. The warranty period is one year starting from the date of acceptance by both parties. During the warranty period, Party A has the right to require Party B to repair any quality problems found within a time limit (except for special circumstances). Party B receives notice from Party A Arrive at the scene for repairs within 1 hour. If Party B fails to start repairs within the time limit specified by Party A or fails to complete the repairs within the time limit specified by Party A, Party A has the right to make repairs by itself, and the cost will be deducted from the warranty deposit. If the warranty deposit is insufficient to pay for the repair costs , in addition to the maintenance costs borne by Party B, Party B will also bear liquidated damages twice the maintenance price to Party A. If the user makes a claim and causes losses to Party A, Party B shall bear double the liability.

9. Insurance and Force Majeure

1. All goods under this contract shall be insured by Party B before they are delivered to Party A for use.

2. When force majeure occurs, the affected party shall immediately notify the other party and issue a notary certificate issued by the place where the force majeure occurred within 14 days, submit it to the other party and obtain approval.

3. Force majeure refers to war, government actions, and fires, floods, hurricanes, earthquakes, social unrest, and strikes that are not the responsibility of both parties.

10. Liability for breach of contract

1. If Party B delays completion or violates relevant agreements, it will be deemed as delaying completion. For each day of delay, Party B shall pay Party A two-thousandth of the total contract price. Liquidated damages, if the total construction period is delayed for more than 20 days, Party A has the right to terminate the contract, and Party B will refund the money paid by Party A and bear the corresponding losses of Party A.

2. If Party B fails to install in accordance with the contract, attachments, drawing design requirements, equipment installation instructions or fails to pass inspection and acceptance by the relevant departments, Party B will unconditionally repair the equipment within the time required by Party A until it meets the quality requirements. After passing the inspection and acceptance by the relevant departments, Party B shall bear the delay in construction period and corresponding liability for breach of contract, and shall compensate Party A for corresponding losses. At the same time, Party A has the right to decide whether to terminate the contract.

3. If either party terminates the contract without authorization, or if the other party terminates the contract due to breach of contract, it shall bear 20% of the contract price for breach of contract.

4. After the elevator installation is completed and has been inspected and accepted by both parties, Party B shall deliver the project in a timely manner, provide complete information required for the acceptance of the installation project, and cooperate with Party A to handle the acceptance filing procedures as required. If Party B delays delivery or delays the acceptance filing for any reason, Party B shall pay Party A a penalty of two thousandths of the total contract amount for each day of delay or delay.

11. Contract Disputes

If any dispute arises between the two parties due to the contract or the execution process, it shall be resolved through friendly negotiation. If no agreement can be reached through negotiation, the dispute may be submitted to the people's court where the project is located for adjudication.

12. Others

1. Before all elevators are delivered for use, Party B is responsible for the safety of all elevators under this contract.

2. Party B guarantees that Party A will not receive any complaints from third parties regarding infringement of patents, trademarks, industrial designs or other intellectual property rights when using goods, services and any part thereof. Party A does not assume any responsibility related to the above issues.

3. If the matters or goods involved in this contract need to be adjusted, Party A’s written consent must be obtained, otherwise Party A will not approve it, and Party B will bear all corresponding responsibilities.

4. Without the prior written consent of Party A, Party B shall not transfer the contract or any part of the contract to any other third party for performance (the installation contract must be installed by an installation company authorized by Party B), otherwise Party A will have the right to terminate the contract and require Party B to pay liquidated damages of 20% of the transfer price.

5. After the elevator is transported to Party A’s construction site, Party B is unable to install it because Party A does not have the installation conditions or there is force majeure. Party A is responsible for the storage and safekeeping of the elevator before the installation period.

6. This contract is made in four copies, with the supplier holding two copies and the demander holding two copies, which have the same legal effect. This contract shall take effect from the date of signature and seal by both parties.

Purchaser:

Representative:

Year, month and day

Unit address:

Postal code:

Telephone:

Fax:

Account opening bank:

Account number:

Supplier:

Representative:

Year, month and day

Unit address:

Postal code:

Telephone:

Fax:

Account opening bank:

Account number:

Part 3: Elevator installation civil engineering construction contract

Party A: ( Tel: 13196393065) Party B: ? (ID number: Tel: 13571681624) Party A needs to install a five-story, five-stop, five-door elevator in the hotel. Party B voluntarily undertakes the civil construction project of the elevator. After repeated negotiations between the two parties, the contract terms were reached as follows:

1. Civil construction period: 20 days. (That is, from July 16 to August 5, 2010, Party A will accept the acceptance on August 6)

2. The total contract price of the civil engineering project: 28,000 yuan

3. Payment method:

① Party A shall pay Party B RMB 5,000 within 7 days of starting work;

② Party A shall pay RMB 5,000 to Party B 15 days after starting work;

③After Party A, together with the elevator purchasing and installation party, inspects and accepts the civil engineering work and completes the installation, commissioning and acceptance of the elevator, when Party A accepts the use of the key, Party A shall pay 15,000 yuan;

④The remaining 3,000 yuan is the warranty deposit. After 3 months of normal operation of the elevator, if there is no problem with the quality of the civil engineering work, Party A will pay the full amount. If any civil engineering problems arise, Party B will maintain and repair them free of charge until the elevator operates normally. (During this period, man-made damage and force majeure damage are excluded.)

4. Party A’s responsibilities:

1. Provide Party B with electricity, water and space during the construction period;

2. During the construction period, coordinate the working relationship between Party B and other construction departments;

3. Ensure the timely payment of project funds and the on-time acceptance of qualified projects;

4 . If Party B discovers buried objects such as pipelines when digging the foundation pit, Party A will compensate Party B.

5. Party B’s responsibilities:

1. Party B is entirely responsible for safety during construction. Party B should attach great importance to safe construction, follow national regulations, strictly operate procedures, safety management, take various safety protection measures, and pay attention to fire prevention, theft prevention, and electricity use at all times. Any unsafe accidents that occur during the construction period will be borne by Party B and Party A will not bear any responsibility.

2. Party B shall strictly follow the construction drawing requirements to ensure the quality of the project. In particular, we must obey and cooperate with the requirements of the elevator purchaser and installer, be fully responsible for the quality and safety of the elevator civil engineering project, ensure the five-story, five-station, and five-door elevator projects, ensure quality and quantity installation, and pass acceptance.

3. All building materials and tools for the civil construction projects used by Party B are purchased, prepared, taken care of and managed by Party B by themselves, and have nothing to do with Party A.

4. Ensure the construction period. If the construction period is delayed, 5% of the total price, calculated on a daily basis, will be deducted by Party A.

6. This contract will be legally effective upon signature.

This contract is made in triplicate, with Party A and Party B each holding one copy.

Signature of Party A: Signature of Party B:

Year?Month?Day