Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

According to the relevant provisions of the Economic Contract Law of the People's Republic of China, this contract is signed by both parties through full consultation.

I. Contents of the contract:

1, _ _ _ _ _ _ _ _ _ Quality requirements:

2. _ _ _ _ _ _ _ _ _ _ _ _ _ Quality requirements:

3. _ _ _ _ _ _ _ _ _ _ _ _ _ Quality requirements:

Second, the contract amount:

* * * RMB (in words) _ _ _ _ _ _ _ (in figures)

Three. Payment terms:

1. After the signing of this contract, Party A shall pay 50% of the total contract amount, namely RMB _ _ _ _ _ _ _ _ (in words: _ _ _ _ _ _ _ _).

2. After the project is completed, Party A shall pay Party B the balance of the contract, namely RMB _ _ _ _ _ _ _ _ (in words: _ _ _ _ _ _).

Four. Responsibilities and obligations:

1. Party B shall complete relevant design and production work according to Party A's requirements.

2. Party B shall complete it within the specified time (before _ _ _ _ _ _ _ _ _) and submit it to Party A for signature.

3. Party A shall provide relevant materials according to Party B's requirements, and bear legal responsibilities and economic disputes caused by copyright and literary responsibility.

Verb (abbreviation for verb) property right agreement:

Party A shall not enjoy the copyright until all the expenses of the commissioned design are settled; otherwise, the copyright of the works designed by Party B shall belong to Party B, and Party A shall not enjoy any rights to the works; If Party A uses or modifies the works designed by Party B without paying the balance, Party B has the right to pursue its legal responsibility according to the Copyright Law of People's Republic of China (PRC).

Liability for breach of contract of intransitive verbs:

Due to the great particularity of the design and production work, it needs the designer's careful creation after a lot of research work, and Party B has fully fulfilled the contract at the beginning of the design. Therefore, if Party A terminates the contract in advance, Party B will not refund the advance payment.

Seven. Other matters:

Eight. In case of any dispute arising from the performance of this contract, Party A and Party B shall settle it through friendly negotiation. If no agreement can be reached, it shall be submitted to legal channels for settlement.

This contract is made in duplicate, one for each party, signed and sealed by the other party, with the same legal effect.

Party A (seal): Party B (seal):

Representative signature: Representative signature:

Address: Address:

Tel: Tel:

Fax: Fax:

Date: Date:

Advertising production contract (2)

Customer (Party A):

Legal representative:

Trustee (Party B):

Legal representative:

In accordance with the Contract Law of People's Republic of China (PRC), Advertising Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B, through friendly negotiation, hereby sign this contract for mutual compliance with the matter that Party A entrusts Party B to design and produce corporate image advertising films of Tiens Group Co., Ltd.

Rule number one Entrusting matters:

1. 1 Design and production content: Party A entrusts Party B to design and produce an advertising film of corporate image (hereinafter referred to as "advertising film"); Party B shall make a shooting plan according to the story board confirmed by Party A, and make it after being approved by Party A. ..

The length and version of 1.2 advertisement: 60s, 30s,15s, 5s TV advertisement and 3 print advertisements.

1.3 number of advertisements: d beta? Digital tape 2 disks

DVD？ 2 discs;

20 flat photos after finishing? Disc 1

3 CD-ROMs of printed advertising products.

Rule number two Design requirements:

2. 1 Specific design requirements: See the first draft of story board and graphic creativity in the attachment "Advertising Film".

Rule three. Remuneration and payment method:

3. 1 The design and manufacturing remuneration of this contract (hereinafter referred to as "remuneration") is RMB? Yuan, in words: RMB: Yuan only.

3.2 On the date of signing this contract, Party A shall pay 60% of Party B's total remuneration, namely RMB Yuan only, as production expenses in advance.

3.3 Party A shall pay 40% of the total remuneration to Party B in a lump sum within 3 working days after Party B completes the production of the advertising film, which is approved by Party A and delivered to the final film.

Article 4? Delivery and acceptance:

4. 1 Party B shall ensure that the expression of its design conforms to the provisions of laws and regulations.

4.2 During the production process, Party B shall produce the musical film in strict accordance with the story board and production requirements of the "advertising film" approved by Party A. Party A accepts the final "advertising film" story board, the first draft of graphic creativity and related production requirements submitted by Party B. If the above requirements cannot be met, Party A has the right to reject the film. Party B shall be instructed to make serious amendments within the time limit determined by both parties through consultation, and the expenses arising therefrom shall be borne by Party B. ..

4.3 Party B shall ensure the production quality of advertising films and strictly follow the broadcasting standards set by national television stations.

Manage pictures and music effects.

4.4 Party A shall make final confirmation within 3 working days after Party B submits the sample, and notify Party B in time.

Finally confirm the result, otherwise it will be regarded as the default.

4.5 If the promotion strategy or product sales strategy of the enterprise or organization advertised in this advertisement changes,

Party B does not assume any responsibility for the failure to broadcast the advertisement due to the change, and at the same time, Party B has the right to collect the production fee in full according to the contract.

4.5 Party B shall, on [20 1 1] [? ] month [? ] recently completed the design of the advertising film under this contract.

And submit the advertisement to Party A for review.

Article 5? intellectual property

5. 1 All rights and interests of the advertising film, including but not limited to intellectual property rights and ownership, belong to Party A. ..

5.2 Party B shall guarantee to independently complete the matters entrusted by Party A, and ensure that the advertising films designed and produced do not have any rights defects in subsequent delivery. If any disputes arise from this, Party B shall bear the responsibilities and compensate Party A for the losses caused thereby.

5.3 Party A guarantees that the contents and all materials of this advertisement are only used for the promotion of this enterprise and shall not be used for other purposes. Otherwise, Party B has the right to charge corresponding fees.

Article 6? Privacy policy

6. 1 Party B has the obligation to keep confidential all information provided by Party A ("confidential information"), and Party B shall not disclose and provide it to any third party without the written permission of Party A;

6.2 Except for the acts authorized by this contract, Party B shall protect the confidential information as a trade secret, and shall not copy or disclose part or all of the confidential information to a third party. Party B may disclose the confidential information provided by the other party to its employees who it knows are only necessary for the purpose of this contract, but at the same time, it shall instruct its employees to abide by the confidentiality and non-disclosure obligations stipulated in this chapter.

6.3 Party B can only copy confidential information to fulfill its obligations under this contract. Party B shall not save graphic materials (including but not limited to raw materials, semi-finished products and finished products) related to design in any way (including but not limited to hard disks, drawings, color samples, photos, films and CDs), and the above materials shall be destroyed or returned to Party A within [3] days after the entrustment is completed or the contract is dissolved. Party B shall return the original materials provided by Party A to Party A within [3] days after the entrusted matters are completed or the Contract is dissolved, and destroy the copies. Party B shall properly keep the confidential information, take full responsibility for the theft, accidental disclosure or other events that damage the confidentiality of the confidential information during Party B's tenure, and compensate for the losses caused to Party A. ..

6.4 This confidentiality clause shall be valid for [1] years after the termination of the contract.

Article 7 Commercial Bribery Clause

In order to protect the legitimate rights and interests of both parties from infringement and maintain the long-term good cooperative relationship between Party A and Party B, Party A and Party B have reached the following agreement in accordance with the Law of People's Republic of China (PRC) on Anti-Unfair Competition, Interim Provisions on Prohibition of Commercial Bribery and relevant laws and regulations:

7. 1 Party A and Party B agree that under no circumstances shall they propose, give, solicit or accept any form of commercial bribery, nor shall they seek any benefits by giving commercial bribery or other rewards. Both parties have the obligation to refuse the bribe of the other employee.

7.2 Gifts and souvenirs received by employees of Party A and Party B from each other in accordance with commercial practices must be uniformly handled by their respective companies. Both parties are obliged to inform each other of this matter.

7.3 In the course of cooperation, if Party A's employees ask for or accept bribes, Party B shall report to Party A in time. ..

7.4 Party B promises to cooperate with Party A to investigate the bribery of its employees.

7.5 If Party B pays bribes to Party A's employees for commercial interests or refuses to ask for bribes from Party A's employees, Party B shall compensate Party A for the losses suffered as a result, and voluntarily accept Party A's deduction of compensation from the payment.

7.6 If Party B violates this article, Party A has the right to unilaterally terminate all contracts or agreements with Party B, and will not bear any liabilities for breach of contract and compensation.

7.7 If Party B actively and comprehensively performs this Agreement and reports to Party A the fact that Party A's employees ask for bribes, Party A will give priority to the development of cooperative relations with them and give priority to the selection of their services under the same conditions; If the report is inconsistent with the facts, Party A has the right to terminate the business cooperation relationship.

Both Party A and Party B have the obligation to restrain their employees to return a certain proportion of the commodity price to the other employee by raising the quotation of the other party's purchased goods; Neither party shall secretly return a certain percentage of the commodity price to the employee of the other party in cash, in kind or by other means.

Article 8? responsibility for breach of contract

8. 1 Any party's failure to perform any obligation under this contract shall be regarded as breach of contract. The breaching party shall bear all losses caused to the other party due to breach of contract;

8.2 If Party B fails to deliver advertising films and print advertisements as agreed in the contract (except for force majeure), Party A has the right to delay or terminate the contract.

8.3 If Party A fails to make payment to Party B as agreed in the contract, Party B has the right to delay or terminate the contract.

8.4 If Party B violates the confidentiality agreement in this contract, Party B shall bear all losses or damages caused to Party A thereby. ..

Article 9? force majeure

9. 1 The term "force majeure" as mentioned in this contract refers to unforeseeable, unavoidable and insurmountable objective conditions due to earthquake, typhoon, flood, fire and war.

9.2 If either party of this contract is unable to perform or fully perform its obligations under this contract due to force majeure, it shall notify the other party in writing within [3] days after the occurrence of force majeure, and provide the other party with the force majeure certificate issued by the relevant department.

9.3 If the contract cannot be performed due to force majeure, it shall be exempted from liability in part or in whole according to the influence of force majeure, unless otherwise stipulated by law. Force majeure after delayed performance of the contract cannot be exempted from liability.

9.4 If the performance of this contract is suspended for 30 days or more due to force majeure, (a) Party A and Party B shall decide whether to continue to perform or terminate this contract through consultation, and sign another agreement for settlement.

Article 10 Law Application and Dispute Resolution

10. 1 This contract is only applicable to the laws of People's Republic of China (PRC).

10.2 Any dispute arising from the performance of this contract can be settled by both parties through consultation. If negotiation fails, either party can submit the dispute to the court where both parties are located for judgment, and the judgment is final and binding on both parties. The judgment fee shall be borne by the losing party.

10.3 when any dispute occurs and any dispute is under arbitration, both parties will continue to implement other parts of the dispute and arbitration that are not involved in this contract except the disputed matters.

Article 11? alteration of contract

1 1. 1 The modification or dissolution of this contract must be in written form.

Article 12? Entry into force of contract and others

12. 1 If any clause of this contract becomes illegal, invalid or unenforceable at any time without fundamentally affecting the effectiveness of this contract, other clauses of this contract will not be affected.

12.2 The titles of all clauses in this contract are for reference only, and the rights and obligations of all parties shall be determined according to the contents of the clauses.

12.3 Without the written permission of the other party, neither party shall use or imitate the other party's business name, trademark, pattern, service mark, symbol, code, model or abbreviation in advertisements or public places, and neither party shall claim ownership of the other party's business name, trademark, pattern, service mark, symbol, code, model or abbreviation.

12.4 nothing in this contract shall be deemed or interpreted as a joint venture or partnership between the two parties.

12.5 this contract supersedes all oral or written meeting minutes, memoranda, contracts and agreements of both parties concerning this contract. The annex is an integral part of this contract and has the same legal effect as this contract.

12.6 this contract shall come into effect as of the date when the authorized representatives of both parties sign and affix their official seals. This contract is made in quadruplicate, three for Party A and one for Party B, all of which are equally authentic. The annexes to this contract are an integral part of this contract and have the same legal effect.

12.7 the notices of both parties concerning the execution of this contract or all matters related to this contract must be sent by written letter or fax or similar communication methods confirmed by both parties at the address in this contract. In the form of letters, it should be delivered by express mail with good reputation. By fax or similar means of communication, the date of notification is the date of communication, and by express mail, the date of notification is the date of mailing and subject to the postmark.

Party A: Party B:

Land? Address:

Legal representative or authorized representative: (signature) Legal representative or authorized representative: (signature)

Electricity? Words:? Electricity? Words:

Pass? Really? Pass? True:

Mail? Editor:? Mail? Editor:

Date of signing: Date of signing:

Advertising production contract (3)

Client:? (hereinafter referred to as Party A)

Contractor: Shanghai Chenyi Advertising Co., Ltd. (hereinafter referred to as Party B)

Through friendly negotiation and based on the principle of mutual respect, Party A entrusts Party B with the production business. In order to clarify the responsibilities of both parties and ensure the completion of the task, both parties jointly abide by the contract, and through consultation, the following agreement is signed for both parties to abide by and implement.

I. Main requirements:

(1) Project name:

(2) Other contents:

(3) Total budgeted expenses (in words):

(4) Methods of providing technical data and drawings:

Second, the production cycle:

What is the content of this contract from? Year? Month? From the date of design and production to the year of AD? Month? Finish before the same day.

Third, the settlement method:

1. On the date of signing this contract, the total expenses paid by Party A to Party B are the advance payment, RMB? Yuan. The balance shall be paid in one lump sum after the acceptance of the project.

2. During the execution of the contract, if the contents added outside the contract are approved by both parties, Party A shall pay 50% of the money first, and the remaining 50% shall be paid in one lump sum after passing the acceptance.

All products are guaranteed for one year. During the warranty period, Party B is unconditionally responsible for the maintenance of the products, and the damage caused by man-made or irresistible factors is not covered by the warranty.

Verb (abbreviation for verb) Other terms:

According to the "People's Republic of China (PRC) Advertising Law" and the provisions of industry regulations, the following explanations are made:

1. The objects, trademarks, words and relevant certification materials of the advertised products are provided by the entrusting party. If there is any falsehood, all responsibilities shall be borne by the entrusting party.

2. When the entrusting party examines and approves the design content, please carefully examine every detail of the project and sign or approve the instructions after examination and approval. If it is confirmed to be wrong, the entrusting party shall bear all the responsibilities and contents.

3. After signing the contract, if there is any unilateral breach, the breaching party will bear all responsibilities. If either party needs to change this contract or other special requirements, it must be agreed by both parties through consultation. Sign a supplementary contract separately.

4. Annex to the contract

1、_____________________

2、_____________________

Verb (abbreviation for verb) dispute resolution:

In case of any dispute during the execution of this contract, both parties shall try their best to solve it through negotiation. If negotiation fails, either party may arbitrate in an arbitration institution with jurisdiction or bring a lawsuit in court.

1. The annexes and supplementary contracts of this contract have the same legal effect as this contract.

2. This contract is made in duplicate, with each party holding one copy.

Party a:? Party B:

Address:? Address:

Telephone:? Contact telephone number:

Business Representative: Business Representative: